Performance of Services The Contractor is responsible for fully meeting all obligations set forth in the Contract and for providing Product in accordance with the Contract or any Authorized User Agreement.
Performance of Service 2.1 Appendix A (General Provisions), Articles 1 through 16, governs the performance of services under this contract. 2.2 Appendix B sets forth the liability and insurance provisions of this contract. 2.3 Appendix C sets forth the services to be performed by the contractor.
Supply of Services 7.1 Supplier shall provide the Services to Purchaser in accordance with the Order in all material respects using reasonable care and skill.
7.2 Supplier shall use reasonable endeavours to meet any performance dates for the Services specified in the Order but any dates shall be estimates only and time shall not be of the essence for the performance of the Services.
7.3 Supplier shall have the right to make any changes to the Services which are necessary to comply with any applicable law or safety requirements or which do not materially affect the nature or quality of the Services.
7.4 Purchaser shall: (a) ensure that the terms of Order are complete and (if submitted by Purchaser) the service specification are complete and accurate; (b) co-operate with Supplier in all matters relating to the Services; (c) provide Supplier, its employees, agents, consultants and subcontractors with access to Purchaser’s premises, machinery and other facilities as reasonably required by Supplier to provide the Services; and (d) provide Supplier with such information and materials as Supplier may reasonably require to supply the Services, and ensure that such information is accurate in all material respects.
7.5 If Supplier’s performance of any of its obligations in respect of the Services is prevented or delayed by an any act or omission by Purchaser or failure by Purchaser to performs its obligations (“Purchaser Default”) Supplier shall without limiting its other rights or remedies have the right to suspend performance of the Services until Purchaser remedied Purchaser Default and relieves Supplier from its obligations to the extent the Customer Default prevents or delays Supplier’s performance. Purchaser shall indemnify Supplier against all liabilities costs, losses and expenses which Supplier may incur by reason of Purchaser Default.
7.6 Where the Services consist of any experimental or developmental work, the results supplied or recommendations made under the Services are given in good faith within the limitations of the data available, but no warranty, expressed or implied, is given as to the ability of Supplier to achieve a specific outcome, nor the accuracy of results obtained.
7.7 Any claims by Purchaser which is based on defect in the Services shall be notified to Supplier within twenty-one (21) days of the services being performed and promptly after discovery of defect or failure. The sole and exclusive remedy of Purchaser for such defect hereunder shall be the re-performance or re- fund, at Supplier’s option, of any defective or non-conforming Services.
Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.
Performance of Work by City If the Contractor fails to perform the Work in accordance with the schedule referred to in section 2 above, the City may, in its discretion, in order to bring the project closer to the schedule, perform or cause to be performed some or all of the Work, and doing so shall not waive any of the City’s rights and remedies. Before doing so, the City shall give the Contractor notice of its intention. The Contractor shall reimburse the City for additional costs incurred by the City in exercising its right to perform or cause to be performed some or all of the Work pursuant to this section.
Maintenance of Services A. Reseller will adopt and adhere to the standards contained in the applicable BellSouth Work Center Interface Agreement regarding maintenance and installation of service.
B. Services resold under the Company’s Tariffs and facilities and equipment provided by the Company shall be maintained by the Company.
C. Reseller or its end users may not rearrange, move, disconnect, remove or attempt to repair any facilities owned by the Company, other than by connection or disconnection to any interface means used, except with the written consent of the Company.
D. Reseller accepts responsibility to notify the Company of situations that arise that may result in a service problem.
E. Reseller will be the Company's single point of contact for all repair calls on behalf of Reseller’s end users. The parties agree to provide one another with toll-free contact numbers for such purposes.
F. Reseller will contact the appropriate repair centers in accordance with procedures established by the Company.
G. For all repair requests, Reseller accepts responsibility for adhering to the Company's prescreening guidelines prior to referring the trouble to the Company.
H. The Company will xxxx Reseller for handling troubles that are found not to be in the Company's network pursuant to its standard time and material charges. The standard time and material charges will be no more than what BellSouth charges to its retail customers for the same services.
I. The Company reserves the right to contact Reseller’s customers, if deemed necessary, for maintenance purposes.
Performance of Work a. Contractor shall perform all Work in a good and workmanlike manner. Contractor shall maintain sufficient staff and crews to perform all Work in an expeditious manner consistent with the interests of the Park District. Contractor shall promptly notify the Park District immediately in writing: (i) of any information required from the Park District and necessary for Contractor to complete its Work in a timely manner; and (ii) of any Work requested by the Park District or required for the project that is not included in the scope of Work reflected in the Contract Documents. Contractor shall be solely responsible for means and methods selected in performing the Work. Contractor shall supervise all Work so that it is performed in a safe and expeditious manner. Contractor shall be solely responsible for the Work of its employees and its subcontractors’ and suppliers’ employees. Contractor shall keep all documents and information related to the project confidential and, except as required by law, shall not disclose such documents or information to any person or other party except the employees of Contractor and its subcontractors who need such documents or information to perform the Work and complete the project.
b. Contractor shall confine all equipment, the storage of materials and the operations of its workers, to limits indicated by law, ordinances, permits, or directions of the Park District and shall not unreasonably encumber the project site with such materials. The project site shall not be utilized for the storage of vehicles, materials, equipment, or fixtures not intended for the Work to be performed.
c. Contractor shall notify all utility companies, public and private, as necessary in advance of commencing performance of the Work. The responsibility for moving water lines, gas lines, wire lines, service connections, water and gas meter boxes, water and gas valve boxes, light standards, cable ways, signals and all other utility appurtenances which are within the limits of the proposed construction will be assumed by the Contractor, at no additional compensation. The Contractor shall verify the location of all utilities prior to the start of construction and shall be responsible for the preservation of existing utility installation and the cost of providing precautionary supports, braces, or other equipment to insure against damage to said utility installation. The cost to repair and replace any new or existing utilities damaged will be paid for by the Contractor.
d. If Contractor uncovers or discovers any concealed condition differing materially from conditions depicted in the Contract Documents or differing from conditions reasonably anticipated or inherent in the Work, Contractor shall immediately stop the Work and notify the Park District of the condition in writing. The Park District shall then issue written directions. Contractor shall not proceed with the Work until the Park District has issued written directions. The contract time and Contract Sum shall be equitably adjusted if necessitated by such directions of the Park District.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
Quality of Services (a) The Consultant shall be responsible for the professional quality, technical accuracy, and the coordination of all designs, drawings, specifications, and other services furnished pursuant to this Agreement.
(b) To that end, the Consultant shall correct or shall revise, without additional compensation, any errors or omissions in its work product or shall make such revisions as are necessary as the result of the failure of the Consultant to provide an accurate, more efficient, and properly constructable product in its designs, drawings, specifications, or other services.
(c) The County's review/approval/acceptance of or payment for the services required by this Agreement shall NOT be construed to operate as a waiver of any rights or of any cause of action arising out of the performance of this Agreement. Additionally, the Consultant shall be and remain liable to the County in accordance with applicable law for all damages to the County caused by the Consultant's negligent performance of any of the services furnished under this Agreement.
(d) The rights and remedies of the County provided for under this Agreement are in addition to any other rights and remedies otherwise provided by law.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
