Permitted Delay. Contractor shall be excused for any delay in performance or completion of the Work caused by (1) acts of God, public utilities or public bodies, (2) the elements beyond average weather conditions for the region, (3) modifications requested by Owner, and (4) other matters Contractor could not reasonably anticipate, control or avoid ("Permitted Delays"). In such event, the Completion Date shall be extended for a period equal to the Permitted Delay to the extent that it affects the critical path for performance of the Work, and provided that Contractor gives Owner written notice of the nature of the delay within twenty-four (24) hours after the delay begins, and under no circumstances shall the time of completion be extended to a date which will prevent Owner from completing the entire project within the time that Owner allows for such completion. Contractor shall not be entitled to any additional compensation for any Permitted Delays.
Permitted Delay. Any delay in construction caused by strike, lockout, war, terrorism, act of God, fire or other casualty, unusually adverse weather conditions, inability to obtain labor or materials or governmental restriction or other act or thing (except Borrower’s lack of funds) beyond the reasonable control of Borrower or Contractor which in fact materially interferes with the ability of Borrower or Contractor to complete the Project, and provided Borrower has notified Lender (1) within ten (10) days of the onset of any such delay specifying the event which may result in such delay and (2) within ten (10) days of the termination of any such delay, and provided further the aggregate extension periods for Permitted Delays shall in no event exceed the period of delay permitted under the Mortgage Loan Documents and the Construction Contract. A delay otherwise constituting a Permitted Delay shall not be a Permitted Delay unless such delay has been consented to by, or will not affect the obligations of, the sureties under any bonds. Permitted Equity Transfers. Transfers of direct or indirect interests in Assignor, provided that such transfers do not result in a Change of Control. Permitted Indebtedness. Indebtedness permitted by §8.1. Permitted Liens. Liens, security interests and other encumbrances permitted by §8.2.
Permitted Delay. Defined in Section 35.
Permitted Delay. The terms “Permitted Delay” and “Permitted Delay Notice” shall have the meanings set forth in Section 6.3 of this Agreement.
Permitted Delay. Permitted Delays may delay the Schedule; however, Owner shall use Best Efforts to minimize the impact of Permitted Delays on the Schedule, and shall, by written notice, keep Charterer informed of such.
Permitted Delay. If a Party determines that the proposed publication --------------- contains patentable subject matter which requires protection, that Party may require the delay of the publication for a period of time not to exceed [***] (or mutually agreed upon time) for the purpose of allowing the pursuit of such protection. If the Sublicensee or Customer objects to the publication that impacts its Project Agreement or license, such publication shall not occur until such consent is given by that Customer or Sublicensee.
Permitted Delay. Notwithstanding Sections 1.1 and 1.2, but subject to the rights of holders of Registrable Securities under Section 2, if the Company shall at any time furnish to each seller of Registrable Securities a certificate signed by the Chief Executive Officer of the Company stating that the Company has pending or in process a material transaction (including a financing transaction), the disclosure of which would, in the reasonable judgment of the Board, materially and adversely affect the Company, the Company may defer the filing (but not the preparation) of a registration statement to be filed pursuant to Section 1.1 or 1.2 for up to 90 days (but the Company shall use its best efforts to complete the transaction and file the registration statement as soon as possible), provided that the Company may not so defer the filing of any such registration statement for more than 120 days in the aggregate in any given one year period.
Permitted Delay. Any delay in construction caused by strike, lockout, war, terrorism, act of God, fire or other casualty, unusually adverse weather conditions, inability to obtain labor or materials or governmental restriction or other act or thing (except Borrower’s or Owner’s lack of funds unless due to the failure of Lender to fund in breach of Lender’s express obligations under this Agreement) beyond the reasonable control of Borrower, Owner, or Contractor which in fact materially interferes with the ability of Owner or Contractor to complete the Project, and provided Borrower has notified Lender (1) within ten (10) days of the onset of any such delay specifying the event which may result in such delay and (2) within ten (10) days of the termination of any such delay, and provided further the aggregate extension periods for Permitted Delays shall in no event exceed the period of delay permitted under the Mortgage Loan Documents and the Construction Contract. A delay otherwise constituting a Permitted Delay shall not be a Permitted Delay unless such delay has been consented to by, or will not affect the obligations of, the sureties under any bonds. Permitted Equity Transfers. Transfers of direct or indirect interests in Borrower, provided that such transfers do not result in a Change of Control.
Permitted Delay. The Company may delay the filing of any Registration Statement or delay or suspend the effectiveness thereof, for a reasonable period of time, but not in excess of 60 consecutive days, if the Board of Directors of the Company determines in its reasonable good faith judgment that such registration would (i) materially interfere with a significant acquisition, corporate organization, financing, securities offering or other similar transaction involving the Company; (ii) require premature disclosure of material information that the Company has a bona fide business purpose for preserving as confidential; (iii) render the Company unable to comply with requirements under the Securities Act or Exchange Act; (iv) require the Company to prepare audited or interim financial statements, whether for itself or for an entity acquired or to be acquired, as of a date other than such entity's fiscal year end, or pro forma financial statements, that are required to be included in the Registration Statement.
Permitted Delay. Subcontractor shall be excused for any delay in performance or completion of the Work caused by (1) acts of God, public utilities or public bodies, (2) the elements,
