Planning and Construction Drawings and Specifications
Planning and Construction Drawings and Specifications Sample Clauses
Related to Planning and Construction Drawings and Specifications
Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Technical Specifications Each Bloom System is an integrated system comprised of a fuel cell stack assembly and associated balance of plant components that converts a fuel into electricity using electrochemical means that (i) has a Nameplate Capacity of at least 0.5 kilowatts of electricity using an electrochemical process and (ii) has an electricity-only generation efficiency greater than thirty percent (30%).
Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.
APPROVAL OF PLANS AND SPECIFICATIONS The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Construction Schedule 5.1 Coordination:
Space Plans Within a commercially reasonable time period after the Execution Date, Tenant shall, at its sole expense (but subject to the Premises Construction Allowance), deliver to Landlord space plans prepared by an architect (“Architect”) chosen by Tenant and reasonably approved by Landlord in electronic Autocad format together with a full-size hard copy depicting all improvements and alterations desired by Tenant to be installed in or made to the Premises. Landlord shall notify Tenant whether it approves of such space plans within five (5) business days after receipt thereof. If Landlord disapproves of the space plans, Landlord shall notify Tenant thereof specifying in reasonable detail the reasons for such disapproval, in which case Tenant shall revise the space plans in accordance with Landlord’s objections and submit revised space plans in accordance with subparagraph (a) above to Landlord for its review and approval. Landlord shall notify Tenant in writing whether or not it approves of the resubmitted space plans within three (3) business days after its receipt thereof and, if Landlord disapproves, Landlord shall notify Tenant thereof specifying in reasonable detail the reasons for such disapproval. This process shall be repeated until the space plans have been finally approved by Landlord and Tenant. If Landlord fails to approve or disapprove of the space plans or the resubmitted space plans, as the case may be, within the applicable time period set forth above in this Section 2.(a), and any such failure is not cured by Landlord within three (3) business days after written notice from Tenant to Landlord of such failure, then the space plans as submitted, or as resubmitted, as the case may be, shall be deemed approved by Landlord. As used herein, “Space Plans” means the Preliminary Spaces Plans finally approved or deemed approved by Landlord as provided above. Material changes to the Space Plans shall require Landlord’s prior consent, which consent shall not be unreasonably withheld, conditioned or delayed. To the extent not attached hereto on the Execution Date, this Work Letter will be automatically amended to include as Annex 1 hereto the finally approved Space Plan.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
