Payment Amounts The aggregate Payments to be made in any fiscal year shall not exceed an amount that is equal to the corresponding Appropriated Amount. (For example, for the Payments due on December 1, 2022, and on June 1, 2023, the aggregate maximum amount of such Payments would be determined by the Appropriated Amount determined for certification by December 1, 2021.) Furthermore, the amount of each such Payment shall not exceed the amount of Incremental Property Tax Revenues (excluding allocations of “back-fill” or “make-up” (payments from the State of Iowa for property tax credits or roll-back) actually received by the City from the Dubuque County Treasurer attributable to the taxable incremental valuation of the Property in the six (6) months immediately preceding the extant Payment due date.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Monthly Payment City shall make monthly payments, based on invoices received, for services satisfactorily performed, and for authorized reimbursable costs incurred. City shall have 30 days from the receipt of an invoice that complies with all of the requirements above to pay Consultant.
Down Payment The Mortgagor has contributed at least 5% of the purchase price for the Mortgaged Property with his/her own funds.
Payment Due Date Unless City notifies the Contractor that a dispute exists, Payment shall be made within [Enter number of days, generally ≥ 30] calendar days, measured from (1) the delivery of goods and/or the rendering of services or (2) the date of receipt of the invoice, whichever is later. Payment is deemed to be made on the date on which City has issued a check to Contractor or, if Contractor has agreed to electronic payment, the date on which City has posted electronic payment to Contractor.
Late Payment Charge If any principal, interest or any other sums due under the Loan Documents (including the amounts due on the Maturity Date) are not paid by Borrower on or prior to the date on which it is due, Borrower shall pay to Lender upon demand an amount equal to the lesser of five percent (5%) of such unpaid sum or the Maximum Legal Rate in order to defray the expense incurred by Lender in handling and processing such delinquent payment and to compensate Lender for the loss of the use of such delinquent payment. Any such amount shall be secured by the Mortgage and the other Loan Documents to the extent permitted by applicable law.
