Power of the Authority to undertake services Sample Clauses

Power of the Authority to undertake services. Notwithstanding anything to the contrary contained in Article 11.1.1 and Article 11.3 of this Agreement, the Authority may, after giving notice to the Service Provider and considering its reply thereto, award any services, contemplated under Article 11.1.1, to any third party on the basis of open competitive bidding (“Bidding Process”). The Service Provider shall have the right of first refusal (“Right of First Refusal”) for matching the financial bid (“Lowest Bid”) of the highest ranked bidder (“Lowest Bidder”) in the Bidding Process, subject to compliance with each of the following terms and conditions (“ROFR Conditions”): A. The Service Provider shall be required to make an upfront payment (“Upfront Payment”) of 1% (one percent) of the Lowest Bid to the Authority; B. The Service Provider has duly satisfied and / or complied with all qualification and eligibility criteria as stipulated by the Authority under the Bidding Process; C. The Service Provider has submitted its financial bid (“Service Provider Bid”) for its selection under the Bidding Process; and D. The Service Provider Bid does not exceed the Lowest Bid by more than 10% (ten percent) of the Lowest Bid as quoted by the Lowest Bidder. In the event that the Service Provider does not exercise its Right of First Refusal under this Agreement, for any reason whatsoever and / or does not comply with any of the ROFR Conditions under this Agreement, the Lowest Bidder shall be selected by the Authority upon completion of the Bidding Process and the Service Provider shall provide access, assistance and co – operation to the Lowest Bidder for undertaking its duties, obligations and responsibilities pursuant to its selection by virtue of the Bidding Process. The Lowest Bidder shall perform its duties, obligations and responsibilities in accordance with the Specifications and Standards and in manner that minimizes disruption in the performance of the duties, obligations and responsibilities of the Service Provider under this Agreement.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Power of the Authority to undertake services

  • Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.

  • Authority to Carry on Business The Trustee represents to the Corporation that at the date of execution and delivery by it of this Indenture it is authorized to carry on the business of a trust company in each of the provinces and territories of Canada but if, notwithstanding the provisions of this Section 14.14, it ceases to be so authorized to carry on business, the validity and enforceability of this Indenture and the Debentures issued hereunder shall not be affected in any manner whatsoever by reason only of such event but the Trustee shall, within 60 days after ceasing to be authorized to carry on the business of a trust company in any of the provinces and territories of Canada, either become so authorized or resign in the manner and with the effect specified in Section 14.2.

  • Information and Services Required of the Owner The Owner shall provide information with reasonable promptness, regarding requirements for and limitations on the Project, including a written program which shall set forth the Owner’s objectives, constraints, and criteria, including schedule, space requirements and relationships, flexibility and expandability, special equipment, systems, sustainability and site requirements.

  • Authority to Enter Agreement Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.

  • Delegation of Authority to Act; Specified Actions 3.4.1 Subject to Section 3.1 and Section 3.2, Xxxxx Bank hereby grants to the Bank Assets Purchaser and Xxxxx Trust Company hereby grants to the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3), as Servicer hereunder, (a) the full right, power and authority to take any action (including any Specified Action) or to omit to take any action (including any Specified Action); provided that no such action or omission shall be taken unless it would be authorized if taken or omitted to be taken by the applicable Seller under the applicable Serviced Corporate Trust Contracts, and (b) all other rights, powers and entitlements of the Sellers under such Serviced Corporate Trust Contracts. In the event the parties identify any duties or obligations that are non-delegable under applicable Law or pursuant to the terms of the Serviced Corporate Trust Contracts, the parties agree to cooperate in good faith to determine how such duties or obligations are to be satisfied in a way to effect the original intent of the parties that the Purchasers have acquired the Business (and control thereof) and are entitled to receive the economic benefits and obligated to bear the economic burdens of the Serviced Appointments. 3.4.2 On the Closing Date, Xxxxx Bank shall execute and deliver to the Bank Assets Purchaser one or more legal powers of attorney in favor of the Bank Assets Purchaser and Xxxxx Trust Company shall execute and deliver to the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3) one or more legal powers of attorney in favor of the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3), in each case, in form and content necessary and effective to authorize such persons to take any action (including any Specified Action) or to omit to take any action (including any Specified Action) and to execute documents or other papers in the applicable Seller’s place and stead, to the fullest extent necessary or appropriate for each applicable Purchaser to exercise the powers and perform the duties provided for hereunder, and following the Closing, the Sellers shall use reasonable best efforts to take all other such actions and execute such other documents as the Purchasers may from time to time reasonably request in order for them to exercise the powers and perform the duties provided for hereunder. For purposes of this Agreement, and without limiting the grant of authority in the preceding sentence, “Specified Action” means any action (including any determination to take no action) with respect to a Serviced Appointment, including any action (or determination to take no action) requiring or permitting the exercise of judgment in connection with decisions between or among alternative courses of action, which may include determinations with respect to the following:

  • Vendor’s Resellers as Related to This Agreement Vendor’s Named Resellers (“Resellers”) under this Agreement shall comply with all terms and conditions of this agreement and all addenda or incorporated documents. All actions related to sales by Authorized Vendor’s Resellers under this Agreement are the responsibility of the awarded Vendor. If Resellers fail to report sales to TIPS under your Agreement, the awarded Vendor is responsible for their contractual failures and shall be billed for the fees. The awarded Vendor may then recover the fees from their named reseller. If there is a dispute between the awarded Vendor and TIPS Member, TIPS or its representatives may, at TIPS sole discretion, assist in conflict resolution if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded Vendor’s TIPS project files, documentation and correspondence related to the requesting TIPS Member’s order. If there are confidentiality requirements by either party, TIPS shall comply to the extent permitted by law. The TIPS Solicitation which resulted in this Vendor Agreement, whether a Request for Proposals, the Request for Competitive Sealed Proposals or Request for Qualifications solicitation, or other, the Vendor’s response to same and all associated documents and forms made part of the solicitation process, including any addenda, are hereby incorporated by reference into this Agreement as if copied verbatim. THE SECTON HEADERS OR TITLES WITHIN THIS DOCUMENT ARE MERELY GUIDES FOR CONVENIENCE AND ARE NOT FOR CLASSIFICATION OR LIMITING OF THE RESPONSIBILITES OF THE PARTIES TO THIS DOCUMENT. Texas governmental entities are prohibited from doing business with companies that fail to certify to this condition as required by Texas Government Code Sec. 2270. By executing this agreement, you certify that you are authorized to bind the undersigned Vendor and that your company (1) does not boycott Israel; and (2) will not boycott Israel during the term of the Agreement. You certify that your company is not listed on and does not and will not do business with companies that are on the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf You certify that if the certified statements above become untrue at any time during the life of this Agreement that the Vendor will notify TIPS within three (3) business day of the change by a letter on Vendor’s letterhead from and signed by an authorized representative of the Vendor stating the non-compliance decision and the TIPS Agreement number and description at: Attention: General Counsel ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx, XX,00000 And by an email sent to xxxx@xxxx-xxx.xxx The undersigned Vendor agrees to maintain the below minimum insurance requirements for TIPS Contract Holders: When the Vendor or its subcontractors are liable for any damages or claims, the Vendor’s policy, when the Vendor is responsible for the claim, must be primary over any other valid and collectible insurance carried by the Member. Any immunity available to TIPS or TIPS Members shall not be used as a defense by the contractor's insurance policy. The coverages and limits are to be considered minimum requirements and in no way limit the liability of the Vendor(s). Insurance shall be written by a carrier with an A-; VII or better rating in accordance with current A.M. Best Key Rating Guide. Only deductibles applicable to property damage are acceptable, unless proof of retention funds to cover said deductibles is provided. "Claims made" policies will not be accepted. Vendor’s required minimum coverage shall not be suspended, voided, cancelled, non-renewed or reduced in coverage or in limits unless replaced by a policy that provides the minimum required coverage except after thirty (30) days prior written notice by certified mail, return receipt requested has been given to TIPS or the TIPS Member if a project or pending delivery of an order is ongoing. Upon request, certified copies of all insurance policies shall be furnished to the TIPS or the TIPS Member. • Orders: All Vendor orders received from TIPS Members must be emailed to TIPS at tipspo@tips- xxx.xxx. Should a TIPS Member send an order directly to the Vendor, it is the Vendor’s responsibility to forward a copy of the order to TIPS at the email above within 3 business days and confirm its receipt with TIPS. • Vendor Encouraging Members to bypass TIPS agreement: Encouraging TIPS Members to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program. • Order Confirmation: All TIPS Member Agreement orders are approved daily by TIPS and sent to the Vendor. The Vendor should confirm receipt of orders to the TIPS Member (customer) within 3 business days. • Vendor custom website for TIPS: If Vendor is hosting a custom TIPS website, updated pricing when effective. TIPS shall be notified when prices change in accordance with the award.

  • Instructions; Authority to Act The Servicer shall be deemed to have received proper instructions with respect to the Receivable Files upon its receipt of written instructions signed by a Trust Officer of the Indenture Trustee.

  • Other Activities of the Adviser The services of the Adviser to the Corporation are not exclusive, and the Adviser may engage in any other business or render similar or different services to others including, without limitation, the direct or indirect sponsorship or management of other investment based accounts or commingled pools of capital, however structured, having investment objectives similar to those of the Corporation, so long as its services to the Corporation hereunder are not impaired thereby, and nothing in this Agreement shall limit or restrict the right of any manager, partner, member (including its members and the owners of its members), officer or employee of the Adviser to engage in any other business or to devote his or her time and attention in part to any other business, whether of a similar or dissimilar nature, or to receive any fees or compensation in connection therewith (including fees for serving as a director of, or providing consulting services to, one or more of the Corporation’s portfolio companies, subject to applicable law). The Adviser assumes no responsibility under this Agreement other than to render the services called for hereunder. It is understood that directors, officers, employees and stockholders of the Corporation are or may become interested in the Adviser and its affiliates, as directors, officers, employees, partners, stockholders, members, managers or otherwise, and that the Adviser and directors, officers, employees, partners, stockholders, members and managers of the Adviser and its affiliates are or may become similarly interested in the Corporation as stockholders or otherwise.

  • Authority to Execute Agreement Each of the Parties represents and warrants that its undersigned representative has been expressly authorized to execute this Agreement for and on behalf of such Party.

  • Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!