Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
Labeling Upon request, Lessee will xxxx the Equipment indicating Lessor's interest with labels provided by Lessor. Lessee will keep all Equipment free from any other marking or labeling which might be interpreted as a claim of ownership.
Product Recalls The Company is not aware of any pattern or series of claims against the Company or any of its subsidiaries which reasonably could be expected to result in a generalized product recall relating to products sold by the Company or any of its subsidiaries, regardless of whether such product recall is formal, informal, voluntary or involuntary.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract. Delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor, unless otherwise agreed to by the Authorized User and the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of a Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case.
Product Data Illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by Developer to illustrate a material, product, or system for some portion of the Work.
Labelling The distributor, on behalf of the selected vendor agrees that all supplies of articles should invariably contain the following information on its label and the carton. One information should not be overlapped by any other information needed to be furnished. The label should contain :
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
