Project Completion Audit Settlement and Closeout
Project Completion Audit Settlement and Closeout Sample Clauses
Related to Project Completion Audit Settlement and Closeout
Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out. a. Coordinate the preparation, acceptance and distribution of project closeout documents in accordance with COUNTY Project Manager or designee procedures to clients.
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Contract Closeout The Provider Agency shall comply with all requirements of Policy Circular P7.01, Contract Closeout, including the timely submittal of the Final Report of Expenditures and any other financial or programmatic reports required by the Department. All required documentation is due within 120 Days of Contract Expiration, Non-renewal or Termination.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
PRICE ESCALATION/DE-ESCALATION (CPI) The County may allow a price escalation provision within this award. The original contract prices shall be firm for an initial one (1) year period. A price escalation/de-escalation will be considered at one (1) year intervals thereafter, provided the Contractor notifies the County, in writing, of the pending price escalation/de-escalation a minimum of sixty (60) days prior to the effective date. Price adjustments shall be based on the latest version of the Consumers Price Index (CPI-U) for All Urban Consumers, All Items, U.S. City Average, non-seasonal, as published by the U.S. Department of Labor, Bureau of Labor Statistics. This information is available at xxx.xxx.xxx. Price adjustment shall be calculated by applying the simple percentage model to the CPI data. This method is defined as subtracting the base period index value (at the time of initial award) from the index value at time of calculation (latest version of the CPI published as of the date of request for price adjustment), divided by the base period index value to identify percentage of change, then multiplying the percentage of change by 100 to identify the percentage change. Formula is as follows: Current Index – Base Index / Base Index = % of Change CPI for current period 232.945 Less CPI for base period 229.815 Equals index point change 3.130 Divided by base period CPI 229.815 Equals 0.0136 Result multiplied by 100 0.0136 x 100 Equals percent change 1.4% % of Change x 100 = Percentage Change CPI-U Calculation Example: A price increase may be requested only at each time interval specified above, using the methodology outlined in this section. To request a price increase, Contractor shall submit a letter stating the percentage amount of the requested increase and adjusted price to the Orange County Procurement Division. The letter shall include the complete calculation utilizing the formula above, and a copy of the CPI-U index table used in the calculation. The maximum allowable increase shall not exceed 4%, unless authorized by the Manager, Procurement Division. All price adjustments must be accepted by the Manager, Procurement Division and shall be memorialized by written amendment to this contract. No retroactive contract price adjustments will be allowed. Should the CPI-U for All Urban Consumers, All Items, U.S City Average, as published by the U.S. Department of Labor, Bureau of Labor Statistics decrease during the term of the contract, or any renewals, the Contractor shall notify the Orange County Procurement Division of price decreases in the method outlined above. If approved, the price adjustment shall become effective on the contract renewal date. If the Contractor fails to pass the decrease on to the County, the County reserves the right to place the Contractor in default, cancel the award, and remove the Contractor from the County Vendor List for a period of time deemed suitable by the County. In the event of this occurrence, the County further reserves the right to utilize any options as stated herein.
Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.
Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
