Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.
Project Changes 1.8.1. All changes shall be administered per the UGC.
1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders.
1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal.
1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form.
1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date".
1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order.
1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order.
1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Shift Changes When an employee is assigned to a specific shift and that assignment is changed, the employee shall be given seven (7) calendar days’ notice prior to the change.
Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.
Allocation Schedule Attached hereto as Exhibit J is an Allocation Schedule, prepared by the Company for illustrative purposes, setting forth: (i) the name of each Company Equity Interest holder; (ii) the number and type of Company Equity Interests held by each such Company Equity Interest holder; (iii) the Fully Diluted Number as of the Execution Date, and the portion thereof attributable to each Company Equity Interest holder; and (iv) the amount of Equity Consideration attributable to each such Company Equity Interest holder’s Company Equity Interests in accordance with the Company LLCA and this Agreement. No later than ten Business Days prior to the Closing, the Company shall deliver to the Buyer an updated Allocation Schedule, prepared in conformance with the principles set forth in Exhibit J, which shall be updated to reflect: (A) the JDA Share Adjustment Amount as of the Closing Date; (B) the Interim Company Financing Cash; (C) the calculation of the Equity Consideration; and (D) the Fully Diluted Number as of the Closing Date; and thereby set forth the final allocation of the Equity Consideration among the holders of Company Equity Interests as of the Effective Time in accordance with the Company LLCA and this Agreement. Following the delivery thereof, the Company will provide the Buyer and their accountants and other Representatives with a reasonable opportunity to review the Allocation Schedule. At least two Business Days prior to the Closing Date, the Buyer may notify the Company of any comments or questions with respect to the Allocation Schedule and the Company shall (x) consider in good faith such comments or questions and (y) prepare and deliver an updated Allocation Schedule to the Company prior to the Closing Date reflecting any agreed upon changes resulting from such comments or questions. Notwithstanding the foregoing, the Allocation Schedule ultimately delivered by the Company to the Buyer in accordance with this Agreement shall control. The Company hereby acknowledges and agrees that the Buyer Parties may rely upon the Allocation Schedule, and in no event will the Buyer or any of its Affiliates (including the Surviving Company) have any liability to any Company Unitholder or other Person with respect to the Allocation Schedule delivered pursuant to this Agreement or on account of shares issued in accordance with the terms hereof as set forth in the Allocation Schedule; provided, that, for the avoidance of doubt, in no event shall the amounts set forth on the Allocation Schedule result in, or require the Buyer to issue a number of XXXX Interests greater, in the aggregate, than the Equity Consideration.
Auction Schedule The Auction Agent shall conduct Auctions in accordance with the schedule set forth below. Such schedule may be changed by the Auction Agent with the consent of the Company, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to each Broker-Dealer. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Company and the Broker-Dealers of the Reference Rate and the Maximum Applicable Rate as set forth in Section 2.2(e)(i) hereof.
Loop Provisioning Involving Integrated Digital Loop Carriers 2.6.1 Where Xxxx has requested an Unbundled Loop and BellSouth uses IDLC systems to provide the local service to the End User and BellSouth has a suitable alternate facility available, BellSouth will make such alternative facilities available to Xxxx. If a suitable alternative facility is not available, then to the extent it is technically feasible, BellSouth will implement one of the following alternative arrangements for Xxxx (e.g. hairpinning):
1. Roll the circuit(s) from the IDLC to any spare copper that exists to the customer premises.
2. Roll the circuit(s) from the IDLC to an existing DLC that is not integrated.
3. If capacity exists, provide "side-door" porting through the switch.
4. If capacity exists, provide "Digital Access Cross Connect System (DACS)- door" porting (if the IDLC routes through a DACS prior to integration into the switch).
2.6.2 Arrangements 3 and 4 above require the use of a designed circuit. Therefore, non- designed Loops such as the SL1 voice grade and UCL-ND may not be ordered in these cases.
2.6.3 If no alternate facility is available, and upon request from Xxxx, and if agreed to by both Parties, BellSouth may utilize its Special Construction (SC) process to determine the additional costs required to provision facilities. Xxxx will then have the option of paying the one-time SC rates to place the Loop.
