Protection of Occupants Sample Clauses

Protection of Occupants. In addition to all other requirements of the Contract Documents, if the Work involves an addition and/or renovation to an existing building, the Design/Builder shall erect and maintain during the progress of the Work suitable dustproof partitions to protect such building and the occupants thereof. If necessary, in the Owner’s or Design/Builder’s judgment or pursuant to manufacturer’s directives or recommendations in order to protect occupants from noxious fumes, odors, or hazardous substances, the Design/Builder may be required to provide additional ventilation and/or work different or extended hours to avoid disruption to other activities within the existing building.
Sample 1Sample 2
AutoNDA by SimpleDocs
Protection of Occupants. In addition to all other requirements of the Contract Documents, if the Work involves an addition or alteration to an existing building, the Contractor shall erect and maintain during the progress of the Work suitable dustproof partitions to protect such building and the occupants thereof. If necessary, in the Owner’s or Contractor’s judgment or pursuant to manufacturer’s directives or recommendations in order to protect occupants from noxious fumes, odors,or hazardous substances, the Contractor may be required to provide additional ventilation and/or work different or extended hours to avoid disruption to other activities within the existing building. Contractorshall protect and keep from harm all occupants of an existing building from construction activities, and shall include a safe pathway into and out of the school.
Sample 1Sample 2

Related to Protection of Occupants

  • Termination of Occupancy Upon termination of occupancy of a County- Assisted Unit by a Tenant, such Unit will be deemed to be continuously occupied by a household of the same income level as the initial income level of the vacating Tenant, until such unit is reoccupied, at which time categorization of the Unit will be established based on the occupancy requirements of Section 2.1.

  • DELAY OF OCCUPANCY If the Premises will not be ready for occupancy by Lessee on the Lease Commencement Date, UTA shall give notice thereof to Lessee and indicate the anticipated date possession of the Premises will be delivered to Lessee. In such case, Lessee shall have the right to terminate the Lease upon written notice to UTA within 7 days after delivery of such notice, but not thereafter. If UTA fails to give notice of delay as set forth above and the Premises are not ready for occupancy by Lessee on the Lease Commencement Date, Lessee may terminate this Lease upon written notice to UTA given prior to the date Lessee is notified the Premises are ready for occupancy, but not thereafter. If, in either case, Lessee does not terminate this Lease, (i) the date the Premises are ready for Lessee’s occupancy shall be deemed the new Lease Commencement Date for all purposes; and (ii) UTA shall not be liable to Lessee for any damages arising from the delay in delivery of the Premises to Lessee, provided that Rent shall be abated as to any period prior to delivery of the Premises to Lessee. If Lessee elects to terminate this Lease, Lessee’s sole remedies in such event shall be to obtain a refund of the Deposit and any pre-paid Rent previously delivered to UTA. Notwithstanding any other provision of this section to the contrary, the rights of Lessee under this section shall not be applicable to any cleaning or repair of the Premises that do not materially interfere with Lessee’s occupancy of the Premises on the Lease Commencement Date.

  • Conditions of Occupancy The Resident may not occupy a Room, unless (i) the Resident is currently enrolled and maintaining status as a full- time student in good standing at the Institution; (ii) this Agreement is executed by all parties; (iii) all Residence Fees then due and payable are paid in full as stated in section 2.03; (iv) the Manager has designated a Room for the Resident and (v) the Resident meets any additional conditions to occupancy established by the Institution, including any vaccination conditions.

  • Certificate of Occupancy The Contractor’s obligation under the Contract is to install the Work in accordance with the Contract Documents, obtain the Certificate of Occupancy from the State Fire Marshal or his deputy, and forward it to the Design Professional as a part of the final close out procedures. The Design Professional’s obligation is to design the Work to comply with the applicable codes and to qualify for a Certificate of Occupancy.

  • Owner Occupancy Participant(s) agree to maintain the property as their primary residence during the term of this Agreement, any extensions thereof, or until closeout, documentation is approved by NCORR. If during the term of the Grant Agreement, Participant(s) (1) use the property as an investment property (2) convert the structure to an ineligible structure type or use, or (3) uses the property as a recreational house or “second” home, then NCORR may require immediate payment in full of the entire grant amount provided to the Participant(s). Participant(s) agree that if during the term of this Agreement, any extensions thereof or prior to closeout, Participant(s) sell part or all of the property without NCORR’s prior written consent, then NCORR may require payment in full the amount of the Grant outstanding at the time of sale.

  • Protection of Improvements So far as practicable, Purchaser shall protect Specified Roads and other improvements (such as roads, trails, telephone lines, ditches, and fences):

  • PARTIAL OCCUPANCY OR USE § 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Design-Builder, provided such occupancy or use is consented to, by endorsement or otherwise, by the insurer providing property insurance and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Design-Builder have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Design-Build Documents. When the Design-Builder considers a portion substantially complete, the Design-Builder shall prepare and submit a list to the Owner as provided under Section 9.8.2. Consent of the Design-Builder to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Design-Builder.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!