Prudential Carve Sample Clauses

Prudential Carve. Out 1. Nothing in this Agreement shall be construed as preventing a Party from adopting or maintaining measures for prudential reasons, such as: (a) the protection of investors, depositors, policy-holders or persons to whom a fiduciary duty is owed by a financial service supplier; or (b) ensuring the integrity and stability of a Party's financial system.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Prudential Carve out 1. Nothing in this Agreement shall be construed to prevent a Party from adopting or maintaining reasonable measures for prudential reasons, such as: (a) the protection of investors, depositors, policy-holders or persons to whom a fiduciary duty is owed by a financial service supplier; (b) the maintenance of the safety, soundness, integrity or financial responsibility of financial service suppliers; or (c) ensuring the integrity and stability of the Party's financial system. 2. These measures shall not be more burdensome than necessary to achieve their aim, and shall not constitute a means of arbitrary or unjustifiable discrimination against financial service suppliers of the other Party in comparison to its own like financial service suppliers, nor shall the measures constitute a disguised restriction on trade in services. 3. Nothing in this Agreement shall be construed as requiring a Party to disclose information relating to the affairs and accounts of individual consumers or to disclose any confidential or proprietary information in the possession of public entities.
Sample 1Sample 2
Prudential Carve. Out 1. Nothing in this Agreement shall be construed to prevent a Party from adopting or maintaining measures for prudential reasons, such as: (a) the protection of investors, depositors, policy-holders or persons to whom a fiduciary duty is owed by a financial service supplier; or (b) ensuring the integrity and stability of a Party's financial system. 2. The measures referred to in paragraph 1 shall not be more burdensome than necessary to achieve their aim. 3. Nothing in this Agreement shall be construed as requiring a Party to disclose information relating to the affairs and accounts of individual consumers or any confidential or proprietary information in the possession of public entities. 4. Each Party shall endeavour to ensure that internationally agreed standards for regulation and supervision in financial services and for the fight against tax evasion and avoidance are implemented and applied in its territory. Such internationally agreed standards are, inter alia, the Core Principle for Effective Banking Supervision of the Basel Committee, the Insurance Core Principles of the International Association of Insurance Supervisors, the Objectives and Principles of Securities Regulation of the International Organization of Securities Commissions, the Agreement on Exchange of Information on Tax Matters of the Organisation for Economic Cooperation and Development, the Statement on Transparency and Exchange of Information for Tax Purposes of the G20 and the Forty Recommendations on Money Laundering and the Nine Special recommendations on Terrorist Financing of the Financial Action Task Force. 5. The Parties take note of the Ten Key Principles for Information Exchange promulgated by the Finance Ministers of the G7 Nations. 6. Without prejudice to other means of prudential regulation of cross-border trade in financial services, a Party may require the registration or authorisation of cross-border financial service suppliers of the other Party and of financial instruments.
Sample 1Sample 2
Prudential Carve out 1. Nothing in this Agreement shall be construed to prevent a Party from adopting or maintaining measures for prudential reasons, such as the protection of investors, depositors, policyholders or persons to whom a fiduciary duty is owed by a financial service supplier, or ensuring the integrity and stability of the financial system. Where such measures do not conform with this Agreement, they shall not be used as a means of avoiding the Party's commitments or obligations under this Agreement. 2. Nothing in this Agreement shall be construed to require a Party to disclose information relating to the affairs and accounts of individual customers or any confidential or proprietary information in the possession of public entities.
Sample 1
Prudential Carve out (39) 1. Each Party may adopt or maintain measures for prudential reasons (40), including: (a) the protection of investors, depositors, policy-holders or persons to whom a fiduciary duty is owed by a financial service supplier; and (b) ensuring the integrity and stability of the Party’s financial system. 2. These measures shall not be more burdensome than necessary to achieve their aim, and where they do not conform to the other provisions of this Agreement, they shall not be used as a means of avoiding each Party’s commitments or obligations under such provisions. 3. Nothing in this Agreement shall be construed to require a Party to disclose information relating to the affairs and accounts of individual consumers or any confidential or proprietary information in the possession of public entities.
Sample 1

Related to Prudential Carve

  • Prudential Bache Securities Inc. ("Prudential-Bache"), a registered broker-dealer, (ii) The Prudential Insurance Company of America ("Prudential"), (iii) Pruco Securities Corporation, a registered broker-dealer, (iv) any Prudential-Bache or Prudential subsidiary or affiliate duly registered as a broker-dealer and/or a transfer agent pursuant to the 1934 Act or (vi) any other Prudential-Bache or Prudential affiliate or subsidiary; provided, however, that PMFS shall be as fully responsible to the Fund for the acts and omissions of any agent or subcontractor as it is for its own acts and omissions.

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Custodial Care Any service or supply, including room and board, which:

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • Enterprise Information Management Standards Grantee shall conform to HHS standards for data management as described by the policies of the HHS Office of Data, Analytics, and Performance. These include, but are not limited to, standards for documentation and communication of data models, metadata, and other data definition methods that are required by HHS for ongoing data governance, strategic portfolio analysis, interoperability planning, and valuation of HHS System data assets.

  • Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:

  • Nurse Representatives & Grievance Committee (a) The Hospital agrees to recognize Association representatives to be elected or appointed from amongst nurses in the bargaining unit for the purpose of dealing with Association business as provided in this Collective Agreement. The number of representatives and the areas which they represent are set out in the Appendix of Local Provisions. (b) The Hospital will recognize a Grievance Committee, one of whom shall be chair. This committee shall operate and conduct itself in accordance with the provisions of the Collective Agreement and the number of nurses on the Grievance Committee is set out in the Appendix of Local Provisions. (c) It is agreed that Union representatives and members of the Grievance Committee have their regular duties and responsibilities to perform for the Hospital and shall not leave their regular duties without first obtaining permission from their immediate supervisor. Such permission shall not be unreasonably withheld. If, in the performance of their duties, a union representative or member of the Grievance Committee is required to enter a unit within the hospital in which they are not ordinarily employed they shall, immediately upon entering such unit, report their presence to the supervisor or nurse in charge, as the case may be. When resuming their regular duties and responsibilities, such representatives shall again report to their immediate supervisor. The Hospital agrees to pay for all time spent during their regular hours by such representatives hereunder.

  • SITE MANAGEMENT We reserve the right, but not the obligation, to: (1) monitor the Site for violations of these Terms of Use; (2) take appropriate legal action against anyone who, in our sole discretion, violates the law or these Terms of Use, including without limitation, reporting such user to law enforcement authorities; (3) in our sole discretion and without limitation, refuse, restrict access to, limit the availability of, or disable (to the extent technologically feasible) any of your Contributions or any portion thereof; (4) in our sole discretion and without limitation, notice, or liability, to remove from the Site or otherwise disable all files and content that are excessive in size or are in any way burdensome to our systems; and (5) otherwise manage the Site in a manner designed to protect our rights and property and to facilitate the proper functioning of the Site.

  • Medical Care The Parents must comply with the School Welfare Officer's recommendations which may include a reasonable decision to release the Pupil home or to his / her education guardian when s/he is unwell.

  • Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!