Quality of Components Sample Clauses

Quality of Components. SANMINA-SCI shall use in its production of Products such Components of a type, quality, and grade specified by CUSTOMER to the extent CUSTOMER chooses to so specify, and shall purchase Components only from Vendors appearing on CUSTOMER's approved vendor list ("AVL"); provided, however, that in the event SANMINA-SCI cannot purchase a Component from a Vendor on CUSTOMER'S AVL for any reason, SANMINA-SCI shall be able to purchase such Component from an alternate Vendor, subject to CUSTOMERS's prior written approval, which approval shall not be unreasonably withheld or delayed.
Sample 1
AutoNDA by SimpleDocs
Quality of Components. MFGR shall use in its production of Products such Components of a type, quality, and grade specified by CUSTOMER to the extent CUSTOMER chooses to so specify, and shall purchase Components only from vendors appearing on CUSTOMER's approved vendor list ("AVL"); provided, however, that in the event MFGR cannot purchase a Component from a vendor on the AVL for any reason, MFGR shall be able to purchase such Component from an alternate vendor, subject to CUSTOMER's prior written approval, which approval shall not be unreasonably withheld or delayed.
Sample 1Sample 2
Quality of Components. SANMINA-SCI shall use in its production of Products such Components of a type, quality, and grade specified by CUSTOMER to the extent CUSTOMER chooses to so specify, and shall purchase Components only from Vendors appearing on CUSTOMER’s approved vendor list (“AVL”); provided, however, that in the event SANMINA-SCI cannot purchase a Component from a Vendor on CUSTOMER’S AVL for any reason, SANMINA-SCI shall be able to purchase such Component from an alternate Vendor, subject to CUSTOMER’s prior written approval, which approval shall not be unreasonably withheld or delayed. SANMINA-SCI will [***], (a) submit to CUSTOMER such number of samples of the Components as CUSTOMER shall reasonably specify prior to the utilization by SANMINA-SCI thereof, and (b) not utilize in the manufacture of the Products the Components until such time as it shall have received from CUSTOMER written notice of its approval of the samples thereof; provided, however, that, unless otherwise agreed, CUSTOMER will reimburse SANMINA-SCI [***] for such samples that are not returned to SANMINA-SCI in a useable form. CUSTOMER shall have [***] of such third party parts samples to respond and propose a parts approval plan.
Sample 1
Quality of Components. SANMINA-SCI shall use in its production of Products such Components of a type, quality, and grade specified by LIFESTREAM to the extent LIFESTREAM chooses to so specify, and shall purchase Components only from Vendors appearing on LIFESTREAM's approved vendor list ("AVL"); provided, however, that in the event SANMINA-SCI cannot purchase a Component from a Vendor on LIFESTREAM'S AVL for any reason, SANMINA-SCI shall be able to purchase such Component from an alternate Vendor, subject to LIFESTREAM's prior written approval, which approval shall not be unreasonably withheld or delayed.
Sample 1
Quality of Components. Benchmark shall use in its manufacture of Products Components of a type, quality, and grade specified by Customer to the extent Customer chooses to so specify in the Specifications and shall purchase Components only from vendors appearing on Customer’s AVL. Customer’s AVL shall designate Customer-approved manufacturers of Components and Component parts, and in the case of an open AVL or deviation from Customer’s AVL or purchase from a non-franchised distributor, Customer shall review and approve in advance such manufacturers or non-franchised distributors on a case-by-case basis, including any specific date and/or lot code restrictive information. Benchmark will not use Components known by Benchmark to be counterfeit Components.
Sample 1
Quality of Components. GENEXEL shall use in its production of Products such Components of a type, quality, and grade specified by LIFESTREAM to the extent LIFESTREAM chooses to so specify, and shall purchase Components only from Vendors appearing on LIFESTREAM's approved vendor list ("AVL"); provided, however, that in the event GENEXEL cannot purchase a Component from a Vendor on LIFESTREAM'S AVL for any reason, GENEXEL shall be able to purchase such Component from an alternate Vendor, subject to LIFESTREAM's prior written approval, which approval shall not be unreasonably withheld or delayed.
Sample 1
Quality of Components. SANMINA-SCI shall use in its production of Products such Components of a type, quality, and grade specified by McDATA to the extent McDATA chooses to so specify, and shall purchase Components only from vendors appearing on McDATA’s approved vendor list (“AVL”); provided, however, that in the event SANMINA-SCI cannot purchase a Component from a vendor on McDATA’S AVL for any reason, SANMINA-SCI shall be able to purchase such Component from an alternate vendor, subject to McDATA’s prior written approval, which approval shall not be unreasonably withheld or delayed.
Sample 1
AutoNDA by SimpleDocs
Quality of Components. Benchmark shall use in its manufacture of Products such Components of a type, quality, and grade specified by Customer to the extent Customer chooses to so specify in the Specifications, and shall purchase Components only from vendors appearing on Customer’s AVL. Customer’s AVL shall designate Customer-approved manufacturers of Components and Component parts, and in the case of an open AVL or deviation from Customer’s AVL or purchase from a non-franchised distributor, Customer shall review and approve such manufacturers or non-franchised distributors on a case-by-case basis, including any specific date and/or lot code restrictive information. Benchmark will not use Components known by Benchmark to be counterfeit Components. Benchmark will develop, maintain (and update as necessary) and execute appropriate quality processes and standards to determine the quality assurance of Components. Inspection of Facility. Upon prior reasonable written notice, Customer may inspect the Products and Components held by Benchmark for Customer at Benchmark’s facilities during Benchmark’s regular business hours, provided that such inspection does not unduly interfere with Benchmark’s operations. Customer and its representatives shall: (a) comply with Benchmark security requirements and execute any requested confidentiality or nondisclosure agreement(s) before entering Benchmark’s premises; and (b) observe all Benchmark safety, security and handling measures.
Sample 1

Related to Quality of Components

  • Quality of Work No Advance or any portion thereof shall be made with respect to defective work or to any contractor that has performed work that is defective and that has not been cured, as confirmed by the report of the Construction Consultant, but Lender may disburse all or part of any Advance before the sum shall become due if Lender believes it advisable to do so, and all such Advances or parts thereof shall be deemed to have been made pursuant to this Agreement.

  • Quality of Services Subject to Section 1.3, Provider shall perform each of the Services (i) in a workmanlike and professional manner, (ii) with the same degree of care as it exercises in performing its own functions of a like or similar nature, (iii) utilizing individuals of suitable experience, training and skill, and (iv) in a timely manner in accordance with the provisions of this Services Agreement.

  • Supply of Materials Unless the parties otherwise agree in a Work Order, Manufacturer will supply, in accordance with the relevant approved raw material specifications, all materials to be used by Manufacturer in the performance of Services under a Work Order other than the Rhythm Materials specified in such Work Order. Rhythm or its designees will provide Manufacturer with the Rhythm Materials. Manufacturer agrees (a) to account for all Rhythm Materials, (b) not to provide Rhythm Materials to any third party (other than an Affiliate acting as a permitted subcontractor) without the express prior written consent of Rhythm, (c) not to use Rhythm Materials for any purpose other than conducting the Services, including, without limitation, not to analyze, characterize, modify or reverse engineer any Rhythm Materials or take any action to determine the structure or composition of any Rhythm Materials unless required * CONFIDENTIAL TREATMENT REQUESTED. OMITTED PORTIONS FILED WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 PROMULGATED UNDER THE SECURITIES ACT OF 1933, AS AMENDED. pursuant to a signed Work Order, and (d) to destroy or return to Rhythm all unused quantities of Rhythm Materials according to Rhythm’s written directions.

  • Product Recall (a) If any governmental agency with jurisdiction over the recall of any goods supplied hereunder provides written notice to Buyer or Seller, or Buyer or Seller has a reasonable basis to conclude, that any goods supplied hereunder could possibly create a potential safety hazard or unsafe condition, pose an unreasonable risk of serious injury or death, contain a defect or a quality or performance deficiency, or are not in compliance with any applicable code, standard or legal requirement so as to make it advisable, or required, that such goods be recalled and/or repaired, Seller or Buyer will promptly communicate such relevant facts to each other. Buyer shall determine whether a recall of the affected goods is warranted or advisable, unless Buyer or Seller has received notice to that effect from any governmental agency with jurisdiction over the recalled goods.

  • Quality of Service At all times, Contractor shall provide Regional Airline Services with appropriate standards of care, but in no event lower than such standards utilized by Continental as of the date of this Agreement. Continental procedures, performance standards and means of measurement thereof concerning the provision of air passenger and air cargo services shall be applicable to all Regional Airline Services provided by Contractor. Contractor shall achieve at least the comparable quality of airline service as provided by Continental, subject to limitations imposed by the type of aircraft used by Contractor, its route network and the availability of equipment and facilities, as compared to those of Continental. Contractor shall comply with all airline customer service commitments or policies of Continental as of the date hereof, including without limitation the "CustomerFirst" commitments, and employee conduct, appearance and training policies in place as of the date hereof, and shall handle customer-related services in a professional, businesslike and courteous manner. In connection therewith, Contractor shall maintain aircraft cleaning cycles and policies, and shall maintain adequate staffing levels, to ensure at least a comparable level of customer service and operational efficiency that Continental achieves, including without limitation in respect of customer complaint response, ticketing and boarding timing, and baggage services. In addition, at the request of Continental, Contractor shall comply with all such airline customer service commitments, policies or standards of care of Continental as adopted, amended or supplemented after the date hereof, provided that Continental shall reimburse Contractor for the reasonable out-of-pocket costs of Contractor of complying with such policies in excess of the costs of complying with such policies as in effect as of the date of this Agreement. Contractor shall provide Continental with timely communication regarding the status of all Scheduled Flights, and shall perform closeout procedures at service levels at least as high as those of Continental at comparably-sized airports. Contractor will use Continental's standard procedures for processing and adjudicating all claims for which Contractor is responsible in an effort to avoid such matters becoming the subject of litigation or insurance claims. Contractor and Continental will periodically meet to discuss and review Contractor's customer service and handling procedures and policies and its employees' conduct, appearance and training standards and policies in an effort to ensure compliance with this Agreement, and to agree to the terms of any necessary corrective action plan and the timing of its implementation.

  • Product Recalls The Company is not aware of any pattern or series of claims against the Company or any of its subsidiaries which reasonably could be expected to result in a generalized product recall relating to products sold by the Company or any of its subsidiaries, regardless of whether such product recall is formal, informal, voluntary or involuntary.

  • Defective Products None of the Group Companies has manufactured, sold or supplied products which are, or were, in any material respect, faulty or defective, or which do not comply in any material respect with any representations or warranties expressly made by such Group Company, or with all applicable regulations, standards and requirements.

  • Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.

  • Review of Materials During the term of this Agreement, Client shall ensure that all prospectuses, statements of additional information, registration statements, proxy statements, reports to shareholders, advertising and sales literature or other materials prepared for distribution to Fund shareholders or the public, which refer to the Subadviser in any way, prepared by employees or agents of Client or its affiliates are consistent with information previously provided by Subadviser. Subadviser shall promptly notify the Client of any changes to information pertaining to the Subadviser and stated in the materials described in this Section 6(g).

  • Product Specifications The Company agrees that all Products sold to Xxxx hereunder shall conform to the respective specifications set forth on Schedule A or to such other specifications as are from time to time agreed upon by the Parties.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!