Revocation of Suspension 22.3.1 In the event that the Authority shall have rectified or removed the cause of Suspension within a period not exceeding 60 (sixty) days from the date of Suspension, it shall revoke the Suspension forthwith and restore all rights of the Contractor under this Agreement. For the avoidance of doubt, the Parties expressly agree that the Authority may, in its discretion, revoke the Suspension at any time, whether or not the cause of Suspension has been rectified or removed hereunder.
22.3.2 Upon the Contractor having cured the Contractor Default within a period not exceeding 60 (sixty) days from the date of Suspension, the Authority shall revoke the Suspension forthwith and restore all rights of the Contractor under this Agreement.
Notice of Suspension The importer and the applicant shall be promptly notified of the suspension of the release of goods according to Article 51.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice.
§ 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination.
§ 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause.
§ 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements.
§ 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.
Initiation of Appeal Following the entry of the Arbitration Award, either party (the “Appellant”) shall have a period of thirty (30) calendar days in which to notify the other party (the “Appellee”), in writing, that the Appellant elects to appeal (the “Appeal”) the Arbitration Award (such notice, an “Appeal Notice”) to a panel of arbitrators as provided in Paragraph 5.2 below. The date the Appellant delivers an Appeal Notice to the Appellee is referred to herein as the “Appeal Date”. The Appeal Notice must be delivered to the Appellee in accordance with the provisions of Paragraph 4.1 above with respect to delivery of an Arbitration Notice. In addition, together with delivery of the Appeal Notice to the Appellee, the Appellant must also pay for (and provide proof of such payment to the Appellee together with delivery of the Appeal Notice) a bond in the amount of 110% of the sum the Appellant owes to the Appellee as a result of the Arbitration Award the Appellant is appealing. In the event an Appellant delivers an Appeal Notice to the Appellee (together with proof of payment of the applicable bond) in compliance with the provisions of this Paragraph 5.1, the Appeal will occur as a matter of right and, except as specifically set forth herein, will not be further conditioned. In the event a party does not deliver an Appeal Notice (along with proof of payment of the applicable bond) to the other party within the deadline prescribed in this Paragraph 5.1, such party shall lose its right to appeal the Arbitration Award. If no party delivers an Appeal Notice (along with proof of payment of the applicable bond) to the other party within the deadline described in this Paragraph 5.1, the Arbitration Award shall be final. The parties acknowledge and agree that any Appeal shall be deemed part of the parties’ agreement to arbitrate for purposes of these Arbitration Provisions and the Arbitration Act.
Service Termination, Cancellation, or Suspension If you wish to cancel the Service, you may contact us as set forth in Section 6 of the General Terms above. Any payment(s) that have begun processing before the requested cancellation date will be processed by us. You agree that we may terminate or suspend your use of the Service at any time and for any reason or no reason. Neither termination, cancellation nor suspension shall affect your liability or obligations under this Agreement.
Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.
Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal.
(b) In the case of a dispute arising from an employee's suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within thirty (30) days of the employee receiving notice of suspension.
EFFECT OF SUSPENSION IN TRADING In the event that on the scheduled Closing Date, either: (a) the NYSE or another primary exchange on which the portfolio securities of the Acquiring Fund or the Acquired Fund are purchased or sold, shall be closed to trading or trading on such exchange shall be restricted; or (b) trading or the reporting of trading on the NYSE or elsewhere shall be disrupted so that accurate appraisal of the value of the net assets of the Acquiring Fund or the Acquired Fund is impracticable, the Closing Date shall be postponed until the first business day after the day when trading is fully resumed and reporting is restored.
Termination; Suspension Your right to use the Online Backup Feature will terminate on expiration of the Service Period. Symantec may immediately suspend or terminate use of the Online Backup Feature during the Service Period for Your failure to or Symantec’s reasonable belief that You have failed to comply with these terms and conditions (other than a trivial or inconsequential breach) or any other misuse of the Online Backup Feature. Following the expiration or termination of the Service Period: Symantec may permanently delete any Data stored to the online backup space provided with Your Software and Services ; Symantec will not be obligated to maintain such Data, forward such Data to You or a third party, or migrate such Data to another backup service or account; and You will not be able to store the Data to any additional backup space that You may have purchased separately unless and until the Service Period is renewed.
