Reimbursement Amount Except for the metropolitan areas listed below, the maximum reimbursement for meals including tax and gratuity, shall be: Breakfast $ 9.00 Lunch $11.00 Dinner $16.00 For the following metropolitan areas the maximum reimbursement shall be: Breakfast $11.00 Lunch $13.00 Dinner $20.00 The metropolitan areas are: Atlanta Boston Cleveland Denver Hartford Kansas City Miami New York City Portland, OR San Francisco St. Louis Baltimore Chicago Dallas/Fort Worth Detroit Houston Los Angeles New Orleans Philadelphia San Diego Seattle Washington D.C. See Appendix L for details related to the boundaries of the above-mentioned metropolitan areas. The metropolitan areas also include any location outside the forty-eight (48) contiguous United States. Employees who meet the eligibility requirements for two (2) or more consecutive meals shall be reimbursed for the actual costs of the meals up to the combined maximum reimbursement amount for the eligible meals.
Settlement Amount If the Non-Defaulting Party has declared an Early Termination Date pursuant to Section 7.2(b), the Non-Defaulting Party shall have the right to (i) accelerate all amounts owing between the Defaulting Party and the Non-Defaulting Party and to liquidate and terminate the undertakings set forth in this Agreement as between the Defaulting Party and the Non-Defaulting Party; and (ii) withhold any payments due to the Defaulting Party under this Agreement pending payment of the Termination Payment. The Non-Defaulting Party will calculate, in a commercially reasonable manner, the Settlement Amount with respect to the Defaulting Party’s obligations under the Agreement and shall net the Settlement Amount in the manner provided for in Section 7.3(c).
Payment Allocation Subject to applicable law, your payments may be applied to what you owe the Credit Union in any manner the Credit Union chooses. However, in every case, in the event you make a payment in excess of the required minimum periodic payment, the Credit Union will allocate the excess amount first to the balance with the highest annual percentage rate and any remaining portion to the other balances in descending order based on applicable annual percentage rate.
Amount The required additional Security shall be in an amount equal to the amount necessary to gross up fully for currently applicable federal and state income taxes the estimated Costs of Local Upgrades and Network Upgrades for which Interconnection Customer previously provided Security. Accordingly, the additional Security shall equal the amount necessary to increase the total Security provided to the amount that would be sufficient to permit the Interconnected Transmission Owner to receive and retain, after the payment of all applicable income taxes (“Current Taxes”) and taking into account the present value of future tax deductions for depreciation that would be available as a result of the anticipated payments or property transfers (the “Present Value Depreciation Amount”), an amount equal to the estimated Costs of Local Upgrades and Network Upgrades for which Interconnection Customer is responsible under the Interconnection Service Agreement. For this purpose, Current Taxes shall be computed based on the composite federal and state income tax rates applicable to the Interconnected Transmission Owner at the time the additional Security is received, determined using the highest marginal rates in effect at that time (the “Current Tax Rate”), and (ii) the Present Value Depreciation Amount shall be computed by discounting the Interconnected Transmission Owner’s anticipated tax depreciation deductions associated with such payments or property transfers by its current weighted average cost of capital.
Funding Amount “Funding Amount” means an amount not to exceed Three Hundred Thousand Dollars ($300,000.00) of tax increment finance revenues to be used for paying the costs associated with the construction, equipping, inspection, and delivery of the Local Public Improvements.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Maximum Total Payment Including the reimbursable expenses shown above (if any), the maximum total payment under this Contract is $ ; this is a not-to-exceed amount, and the District will not pay more than this amount unless specifically agreed to in an amendment executed by the parties.
Over-Allowance Amount On the Cost Proposal Delivery Date and, in any event, prior to the commencement of the construction of the Tenant Improvements, Tenant shall deliver to Landlord cash in an amount (the “Over-Allowance Amount”) equal to the difference between (i) the amount of the Cost Proposal and (ii) the amount of the Tenant Improvement Allowance (less any portion thereof already disbursed by Landlord, or in the process of being disbursed by Landlord, on or before the Cost Proposal Delivery Date). The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. If, after the Cost Proposal Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or the Tenant Improvements as a result of requests made by Tenant or as otherwise specified in Section 5.01(h) below, any additional costs which arise in connection with such revisions, changes or substitutions shall be paid by Tenant to Landlord immediately upon Landlord’s request as an addition to the Over-Allowance Amount and, in any event, prior to the commencement of the construction of the revisions, changes or substitutions. Promptly following completion of construction of the Tenant Improvements and payment of all costs incurred in connection therewith, Landlord shall prepare and deliver to Tenant a reasonably detailed reconciliation of (i) the total cost of the Tenant Improvements, including all Tenant Improvement Allowance Items, and (ii) the total amount of the Tenant Improvement Allowance and the Over-Allowance Amount payments previously made by Tenant pursuant to the foregoing provisions of this Section. To the extent that such reconciliation discloses that the total costs of the Tenant Improvements exceeds the amount of the Tenant Improvement Allowance plus all Over-Allowance Amount previously paid by Tenant, Tenant shall pay the amount of such shortfall to Landlord within thirty (30) days after receipt of such reconciliation. To the extent that such reconciliation discloses that the total costs of the Tenant Improvements is less than the amount of the Tenant Improvement Allowance plus all Over-Allowance Amounts previously paid by Tenant, Landlord shall pay the amount of such overage to Tenant at the time that Landlord delivers such reconciliation to Tenant.
Returned Payment Fee If your account is subject to a Returned Payment Fee, the fee will be charged to your account when a payment is returned for any reason.
Consideration Payment 5.1 In consideration of the Company’s Services, the Client shall pay to the Company the Consideration to be stipulated in the Termsheet and all reasonable out of pocket expenses (if any) in accordance with the commercial terms and payment terms as detailed in the Separate Agreement.
5.2 The Company shall send its staff to check for the quality of completion of the Project(s) together with the Client. The Client shall pay for the Company’s Services within 90 days upon the completion of the Project(s) to the satisfaction of the Client.
5.3 The Company shall be entitled to the receivables from the Client for the percentage of Work completed. The date of payment of such Work is stated in the Termsheets and unless the Company is not satisfied with the quality of Work completed and/or the Client has not fulfilled the terms and conditions specified under the Termsheets.
