Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Completion and Recordation of Assignments of Mortgage As soon as practicable after the Closing Date, the Servicing Transfer Date or the date on which a Qualifying Substitute Mortgage Loan is delivered pursuant to Section 2.05 of the Trust Agreement, as applicable (but in no event more than 90 days thereafter except to the extent delays are caused by the applicable public recording office), the Servicer shall cause the endorsements on the Mortgage Note (if applicable), and the Assignments of Mortgage (subject to Section 3.01(a)) to be completed in the name of the Trustee (or MERS, as applicable).
Enforcement of Due-on-Sale Clauses; Assumption and Modification Agreements; Certain Assignments (a) When any Mortgaged Property is conveyed by the Mortgagor, the Master Servicer or Subservicer, to the extent it has knowledge of such conveyance, shall enforce any due-on-sale clause contained in any Mortgage Note or Mortgage, to the extent permitted under applicable law and governmental regulations, but only to the extent that such enforcement will not adversely affect or jeopardize coverage under any Required Insurance Policy. Notwithstanding the foregoing: (i) the Master Servicer shall not be deemed to be in default under this Section 3.13(a) by reason of any transfer or assumption which the Master Servicer is restricted by law from preventing; and (ii) if the Master Servicer determines that it is reasonably likely that any Mortgagor will bring, or if any Mortgagor does bring, legal action to declare invalid or otherwise avoid enforcement of a due-on-sale clause contained in any Mortgage Note or Mortgage, the Master Servicer shall not be required to enforce the due-on-sale clause or to contest such action. (b) Subject to the Master Servicer's duty to enforce any due-on-sale clause to the extent set forth in Section 3.13(a), in any case in which a Mortgaged Property is to be conveyed to a Person by a Mortgagor, and such Person is to enter into an assumption or modification agreement or supplement to the Mortgage Note or Mortgage which requires the signature of the Trustee, or if an instrument of release signed by the Trustee is required releasing the Mortgagor from liability on the Mortgage Loan, the Master Servicer is authorized, subject to the requirements of the sentence next following, to execute and deliver, on behalf of the Trustee, the assumption agreement with the Person to whom the Mortgaged Property is to be conveyed and such modification agreement or supplement to the Mortgage Note or Mortgage or other instruments as are reasonable or necessary to carry out the terms of the Mortgage Note or Mortgage or otherwise to comply with any applicable laws regarding assumptions or the transfer of the Mortgaged Property to such Person; provided, however, none of such terms and requirements shall either (i) both (A) constitute a "significant modification" effecting an exchange or reissuance of such Mortgage Loan under the REMIC Provisions and (B) cause any portion of any REMIC formed under the Series Supplement to fail to qualify as a REMIC under the Code or (subject to Section 10.01(f)), result in the imposition of any tax on "prohibited transactions" or (ii) constitute "contributions" after the start-up date under the REMIC Provisions. The Master Servicer shall execute and deliver such documents only if it reasonably determines that (i) its execution and delivery thereof will not conflict with or violate any terms of this Agreement or cause the unpaid balance and interest on the Mortgage Loan to be uncollectible in whole or in part, (ii) any required consents of insurers under any Required Insurance Policies have been obtained and (iii) subsequent to the closing of the transaction involving the assumption or transfer (A) the Mortgage Loan will continue to be secured by a first mortgage lien pursuant to the terms of the Mortgage, (B) such transaction will not adversely affect the coverage under any Required Insurance Policies, (C) the Mortgage Loan will fully amortize over the remaining term thereof, (D) no material term of the Mortgage Loan (including the interest rate on the Mortgage Loan) will be altered nor will the term of the Mortgage Loan be changed and (E) if the seller/transferor of the Mortgaged Property is to be released from liability on the Mortgage Loan, such release will not (based on the Master Servicer's or Subservicer's good faith determination) adversely affect the collectability of the Mortgage Loan. Upon receipt of appropriate instructions from the Master Servicer in accordance with the foregoing, the Trustee shall execute any necessary instruments for such assumption or substitution of liability as directed in writing by the Master Servicer. Upon the closing of the transactions contemplated by such documents, the Master Servicer shall cause the originals or true and correct copies of the assumption agreement, the release (if any), or the modification or supplement to the Mortgage Note or Mortgage to be delivered to the Trustee or the Custodian and deposited with the Mortgage File for such Mortgage Loan. Any fee collected by the Master Servicer or such related Subservicer for entering into an assumption or substitution of liability agreement will be retained by the Master Servicer or such Subservicer as additional servicing compensation. (c) The Master Servicer or the related Subservicer, as the case may be, shall be entitled to approve a request from a Mortgagor for a partial release of the related Mortgaged Property, the granting of an easement thereon in favor of another Person, any alteration or demolition of the related Mortgaged Property (or, with respect to a Cooperative Loan, the related Cooperative Apartment) without any right of reimbursement or other similar matters if it has determined, exercising its good faith business judgment in the same manner as it would if it were the owner of the related Mortgage Loan, that the security for, and the timely and full collectability of, such Mortgage Loan would not be adversely affected thereby and that any portion of any REMIC formed under the Series Supplement would not fail to continue to qualify as a REMIC under the Code as a result thereof and (subject to Section 10.01(f)) that no tax on "prohibited transactions" or "contributions" after the startup day would be imposed on any such REMIC as a result thereof. Any fee collected by the Master Servicer or the related Subservicer for processing such a request will be retained by the Master Servicer or such Subservicer as additional servicing compensation. (d) Subject to any other applicable terms and conditions of this Agreement, the Trustee and Master Servicer shall be entitled to approve an assignment in lieu of satisfaction with respect to any Mortgage Loan, provided the obligee with respect to such Mortgage Loan following such proposed assignment provides the Trustee and Master Servicer with a "Lender Certification for Assignment of Mortgage Loan" in the form attached hereto as Exhibit M, in form and substance satisfactory to the Trustee and Master Servicer, providing the following: (i) that the substance of the assignment is, and is intended to be, a refinancing of such Mortgage; (ii) that the Mortgage Loan following the proposed assignment will have a rate of interest at least 0.25 percent below or above the rate of interest on such Mortgage Loan prior to such proposed assignment; and (iii) that such assignment is at the request of the borrower under the related Mortgage Loan. Upon approval of an assignment in lieu of satisfaction with respect to any Mortgage Loan, the Master Servicer shall receive cash in an amount equal to the unpaid principal balance of and accrued interest on such Mortgage Loan and the Master Servicer shall treat such amount as a Principal Prepayment in Full with respect to such Mortgage Loan for all purposes hereof.
Further Assurances; Change in Name or Jurisdiction of Origination, etc (i) The Borrower hereby authorizes and hereby agrees from time to time, at its own expense, promptly to execute (if necessary) and deliver all further instruments and documents, and to take all further actions, that may be necessary or desirable, or that the Administrative Agent may reasonably request, to perfect, protect or more fully evidence the security interest granted pursuant to this Agreement or any other Transaction Document, or to enable the Administrative Agent (on behalf of the Secured Parties) to exercise and enforce the Secured Parties’ rights and remedies under this Agreement and the other Transaction Document. Without limiting the foregoing, the Borrower hereby authorizes, and will, upon the request of the Administrative Agent, at the Borrower’s own expense, execute (if necessary) and file such financing statements or continuation statements, or amendments thereto, and such other instruments and documents, that may be necessary, or that the Administrative Agent may reasonably request, to perfect, protect or evidence any of the foregoing. (ii) The Borrower authorizes the Administrative Agent to file financing statements, continuation statements and amendments thereto and assignments thereof, relating to the Receivables, the Related Security, the related Contracts, Collections with respect thereto and the other Collateral without the signature of the Borrower. A photocopy or other reproduction of this Agreement shall be sufficient as a financing statement where permitted by law. (iii) The Borrower shall at all times be organized under the laws of the State of Delaware and shall not take any action to change its jurisdiction of organization. (iv) The Borrower will not change its name, location, identity or corporate structure unless (x) the Borrower, at its own expense, shall have taken all action necessary or appropriate to perfect or maintain the perfection of the security interest under this Agreement (including, without limitation, the filing of all financing statements and the taking of such other action as the Administrative Agent may request in connection with such change or relocation) and (y) if requested by the Administrative Agent, the Borrower shall cause to be delivered to the Administrative Agent, an opinion, in form and substance satisfactory to the Administrative Agent as to such UCC perfection and priority matters as the Administrative Agent may request at such time.
Waivers and Amendments; Non-Contractual Remedies; Preservation of Remedies This Guaranty may be amended, superseded, canceled, renewed or extended, and the terms hereof may be waived, only by a written instrument signed by the parties or, in the case of a waiver, by the party waiving compliance. No delay on the part of any party on exercising any right, power or privilege hereunder shall operate as a waiver thereof, nor shall any waiver on the part of any party of any right, power or privilege, nor any single or partial exercise of any such right, power or privilege, preclude any further exercise thereof or the exercise of any other such right, power or privilege. The rights and remedies herein provided are cumulative and are not exclusive of any rights or remedies that any party may otherwise have at law or in equity.
Restoration of Rights on Abandonment of Proceedings In case the Trustee shall have proceeded to enforce any right under this Indenture and such proceedings shall have been discontinued or abandoned for any reason, or shall have been determined adversely to the Trustee, then and in every such case the Issuer and the Trustee shall be restored respectively to their former positions and rights hereunder, and all rights, remedies and powers of the Issuer, the Trustee and the Securityholders shall continue as though no such proceedings had been taken.
Terms of procurement Terms of submission: Electronic submission: Required Languages in which tenders or requests to participate may be submitted: English Electronic catalogue: Not allowed Deadline for receipt of tenders: 20240219Z 12:00:00Z Information about public opening: Terms of contract: Electronic invoicing: Required
Enforcement of Due-On-Sale Clauses; Assumption Agreements (a) Except as otherwise provided in this Section, when any property subject to a Mortgage has been conveyed by the Mortgagor, the Master Servicer shall to the extent that it has knowledge of such conveyance, enforce any due-on-sale clause contained in any Mortgage Note or Mortgage, to the extent permitted under applicable law and governmental regulations, but only to the extent that such enforcement will not adversely affect or jeopardize coverage under any Required Insurance Policy. Notwithstanding the foregoing, the Master Servicer is not required to exercise such rights with respect to a Mortgage Loan if the Person to whom the related Mortgaged Property has been conveyed or is proposed to be conveyed satisfies the terms and conditions contained in the Mortgage Note and Mortgage related thereto and the consent of the mortgagee under such Mortgage Note or Mortgage is not otherwise so required under such Mortgage Note or Mortgage as a condition to such transfer. In the event that the Master Servicer is prohibited by law from enforcing any such due-on-sale clause, or if coverage under any Required Insurance Policy would be adversely affected, or if nonenforcement is otherwise permitted hereunder, the Master Servicer is authorized, subject to Section 3.10(b), to take or enter into an assumption and modification agreement from or with the person to whom such property has been or is about to be conveyed, pursuant to which such person becomes liable under the Mortgage Note and, unless prohibited by applicable state law, the Mortgagor remains liable thereon, provided that the Mortgage Loan shall continue to be covered (if so covered before the Master Servicer enters such agreement) by the applicable Required Insurance Policies. The Master Servicer, subject to Section 3.10(b), is also authorized with the prior approval of the insurers under any Required Insurance Policies to enter into a substitution of liability agreement with such Person, pursuant to which the original Mortgagor is released from liability and such Person is substituted as Mortgagor and becomes liable under the Mortgage Note. Notwithstanding the foregoing, the Master Servicer shall not be deemed to be in default under this Section by reason of any transfer or assumption which the Master Servicer reasonably believes it is restricted by law from preventing, for any reason whatsoever. (b) Subject to the Master Servicer's duty to enforce any due-on-sale clause to the extent set forth in Section 3.10(a) hereof, in any case in which a Mortgaged Property has been conveyed to a Person by a Mortgagor, and such Person is to enter into an assumption agreement or modification agreement or supplement to the Mortgage Note or Mortgage that requires the signature of the Trustee, or if an instrument of release signed by the Trustee is required releasing the Mortgagor from liability on the Mortgage Loan, the Master Servicer shall prepare and deliver or cause to be prepared and delivered to the Trustee for signature and shall direct, in writing, the Trustee to execute the assumption agreement with the Person to whom the Mortgaged Property is to be conveyed and such modification agreement or supplement to the Mortgage Note or Mortgage or other instruments as are reasonable or necessary to carry out the terms of the Mortgage Note or Mortgage or otherwise to comply with any applicable laws regarding assumptions or the transfer of the Mortgaged Property to such Person. In connection with any such assumption, no material term of the Mortgage Note may be changed. In addition, the substitute Mortgagor and the Mortgaged Property must be acceptable to the Master Servicer in accordance with its underwriting standards as then in effect. Together with each such substitution, assumption or other agreement or instrument delivered to the Trustee for execution by it, the Master Servicer shall deliver an Officer's Certificate signed by a Servicing Officer stating that the requirements of this subsection have been met in connection therewith. The Master Servicer shall notify the Trustee that any such substitution or assumption agreement has been completed by forwarding to the Trustee the original of such substitution or assumption agreement, which in the case of the original shall be added to the related Mortgage File and shall, for all purposes, be considered a part of such Mortgage File to the same extent as all other documents and instruments constituting a part thereof. Any fee collected by the Master Servicer for entering into an assumption or substitution of liability agreement will be retained by the Master Servicer as additional servicing compensation.
Direction of Proceedings and Waiver of Defaults by Majority of Noteholders The Holders of not less than a majority in aggregate principal amount of the Notes at the time outstanding shall have the right to direct the time, method and place of conducting any proceeding for any remedy available to the Trustee or exercising any trust or power conferred on the Trustee; provided, that (a) such direction shall not be in conflict with any rule of law or with this Indenture, (b) the Trustee may take any other action which is not inconsistent with such direction, (c) the Trustee may decline to take any action that would benefit some Noteholders to the detriment of other Noteholders or otherwise be unduly prejudicial to the Noteholders not joining therein and (d) the Trustee may decline to take any action that would involve the Trustee in personal liability. Prior to taking any such action hereunder, the Trustee shall be entitled to indemnification reasonably satisfactory to it in its sole discretion against all losses and expenses caused by taking or not taking such action. The Holders of a majority in aggregate principal amount of the Notes at the time outstanding may, on behalf of the Holders of all of the Notes, waive any past Default or Event of Default hereunder and its consequences except (i) a default in the payment of the principal of (including the Redemption Price upon redemption pursuant to Article 3 hereof), premium, if any, or interest on the Notes, unless such default has been cured and the Issuer or the Guarantor has deposited with the Trustee all required payments of the principal of, premium, if any, and interest on the Notes (provided, however, that the Holders of a majority in aggregate principal amount of the Notes then outstanding may rescind an acceleration and its consequences, including any related payment default that resulted from such acceleration) or (ii) a default in respect of a covenant or provisions hereof which under Article 9 hereof cannot be modified or amended without the consent of the Holders of all Notes then outstanding or each Note affected thereby. Upon any such waiver, the Issuer, the Trustee and the Holders of the Notes shall be restored to their former positions and rights hereunder; but no such waiver shall extend to any subsequent or other Default or Event of Default or impair any right consequent thereon. Whenever any Default or Event of Default hereunder shall have been waived as permitted by this Section 6.07, said Default or Event of Default shall for all purposes of the Notes and this Indenture be deemed to have been cured and to be not continuing; but no such waiver shall extend to any subsequent or other Default or Event of Default or impair any right consequent thereon.
Construction of Provisions Although certain provisions of this Agreement contain express language which precludes the Servicer's recovery of, or reimbursement for, expenses incurred hereunder, no inference to the contrary shall be drawn from absence of such, or similar, language in any other provision hereof regarding expenses.