Service Interruption Landlord shall not be liable in damages for any failure or interruption of any utility service to the Premises, except to the extent that any failure or interruption arises from the gross negligence or willful misconduct of Landlord. No failure or interruption of utility service for any reason shall entitle Tenant to terminate this Lease; provided, however, that if the failure or interruption of any Service to be repaired or maintained by Landlord and not the service provider continues for a period of forty-eight (48) hours or more, Tenant shall be entitled to an equitable abatement of Minimum Rent. Landlord shall not be obligated to provide any service or maintenance or to make any repairs pursuant to this Lease when such service, maintenance or repair is made necessary because of any wrongful act or misuse of any utility service by Tenant, Tenant's agents, employees, servants, contractors, subtenants or licensees. Landlord reserves the right to stop any Service when Landlord deems such stoppage necessary, whether by reason of accident or emergency, or for repairs or improvements or otherwise, provided, that any such period of stoppage shall be only so long as is reasonably required to effect any necessary repairs or maintenance. Landlord shall not be obligated to inspect the Premises and shall not be obligated to make any repairs or perform any maintenance hereunder unless first notified of the need thereof in writing or, in an emergency, verbally, followed by a written confirmation, by Tenant. Upon receipt of any such notice, Landlord shall commence any required repair work of an emergency nature as soon as possible and work as expeditiously as possible to complete such work. All other work of a non-emergency nature shall be performed as promptly as possible. If Landlord shall fail to commence emergency repairs or maintenance to be performed by Landlord and not the service provider within twenty-four (24) hours after said notice, or non-emergency repairs or maintenance within five (5) days after said notice, then Tenant shall be entitled to an equitable abatement of Minimum Rent for so long as such failure continues and an extension of the Lease Term for a period equal to the period of rent abatement.
Service Interruptions When necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements which in the reasonable judgment of Landlord are desirable or necessary to be made, or by reason of event(s) of Force Majeure, Landlord reserves the right to interrupt, curtail, stop or suspend (i) the furnishing of heating, elevator, air conditioning, and cleaning services and (ii) the operation of the plumbing and electric systems. Landlord shall exercise reasonable diligence to eliminate the cause of any such interruption, curtailment, stoppage or suspension, but there shall be no diminution or abatement of rent or other compensation due from Landlord to Tenant hereunder, nor shall this Lease be affected or any of the Tenant’s obligations hereunder reduced, and the Landlord shall have no responsibility or liability for any such interruption, curtailment, stoppage, or suspension of services or systems, except as provided herein. Landlord shall schedule all non-emergency interruptions, curtailments, stops or suspensions of services or systems in advance after consultation with Tenant, and shall make commercially reasonable efforts to avoid the same interfering with Tenant’s business. Notwithstanding the foregoing, Tenant shall be entitled to a proportionate abatement of Base Rent in the event of a Landlord Service Interruption (as defined below). For the purposes hereof, a “Landlord Service Interruption” shall occur in the event (i) the Premises shall lack any service which Landlord is required to provide hereunder thereby rendering at least fifty (50%) percent of the usable area of the Premises untenantable for the entirety of the Landlord Service Interruption Cure Period (as defined below), (ii) such lack of service was not caused by the act or omission of Tenant or any Tenant Party; (iii) Tenant in fact ceases to use at least fifty (50%) percent of the Premises for the entirety of the Landlord Service Interruption Cure Period; and (iii) such interruption of service was the result of causes, events or circumstances within the Landlord’s reasonable control and the cure of such interruption is within Landlord’s reasonable control. During such Landlord Service Interruption Period, Landlord will, if reasonably practical, cooperate with Tenant to arrange for the provision of any interrupted services on an interim basis via temporary measures until final corrective measures can be accomplished and Tenant will permit Landlord the necessary access to the Premises to remedy such lack of service, subject to the provisions of Section 9.06. For the purposes hereof, the “Landlord Service Interruption Cure Period” shall be defined as seven (7) consecutive Business Days after Landlord’s receipt of written notice from Tenant of the Landlord Service Interruption. This Section 6.03 shall be Tenant’s sole and exclusive remedy on account of an interruption of services or Landlord default resulting in an interruption of services other than Tenant’s right to obtain affirmative injunctive relief. This Section 6.03 shall not apply to any interruption or failure of services required to be provided by Landlord under Section 6.02(a) or Exhibit E attached hereto, which is caused in whole or in part by any act or omission of Tenant or any Tenant Party, or by any occurrence described in Section 16.09, or by any cause whatsoever other than those set forth in the first sentence of this Section 6.03. Notwithstanding the foregoing, if either Landlord or Tenant disputes in good faith whether, or the extent to which, an event is subject to the provisions of this Section 6.03, or the amount of Tenant’s abatement of Base Rent hereunder, such dispute shall be resolved in accordance with Section 16.17 of this Lease; provided, however, that in the event that it is ultimately determined that there was a Landlord Service Interruption, then Tenant shall have the right to a retroactive equitable abatement of Base Rent for the period as set forth above, provided that, if the Term expires before Tenant’s entire retroactive abatement has been effected, then Landlord shall immediately refund to Tenant any overpayment of Rent due under the Lease not yet received on account of the retroactive abatement.
Delays If no event of Force Majeure shall have occurred and be continuing and in the event that a delay shall have been caused by the negligence or willful misconduct of the Custodian in carrying out an Instruction to credit or transfer cash, the Custodian shall be liable to the Fund: (a) with respect to Principal Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Custodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected; and, (b) with respect to Agency Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Subcustodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected. The Custodian shall not be liable for delays in carrying out Instructions to transfer cash which are not due to the Custodian's own negligence or willful misconduct.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Shortages Claims for shortages in the amount of Products shipped by Patheon will be dealt with by reasonable agreement of the parties.
Interruptions There shall be no abatement of rent and Lessor shall not be liable in any respect whatsoever for the inadequacy, stoppage, interruption or discontinuance of any utility or service due to riot, strike, labor dispute, breakdown, accident, repair or other cause beyond Lessor's reasonable control or in cooperation with governmental request or directions.
Force Majeure Events The Parties shall be excused from any failure to perform any obligation hereunder to the extent such failure is caused by a Force Majeure Event. A Force Majeure Event shall operate to excuse a failure to perform an obligation hereunder only for the period of time during which the Force Majeure Event renders performance impossible or infeasible and only if the Party asserting Force Majeure as an excuse for its failure to perform has provided written notice to the other Party specifying the obligation to be excused and describing the events or conditions constituting the Force Majeure Event. As used herein, “Force Majeure Event” means the occurrence of an event or circumstance beyond the reasonable control of the party failing to perform, including, without limitation, (a) explosions, fires, flood, earthquakes, catastrophic weather conditions, or other elements of nature or acts of God; (b) acts of war (declared or undeclared), acts of terrorism, insurrection, riots, civil disorders, rebellion or sabotage; (c) acts of federal, state, local or foreign governmental authorities or courts; (d) labor disputes, lockouts, strikes or other industrial action, whether direct or indirect and whether lawful or unlawful; (e) failures or fluctuations in electrical power or telecommunications service or equipment; and (f) delays caused by the other Party’s nonperformance hereunder.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Mail Service Interruption If by reason of any interruption of mail service, actual or threatened, any notice to be given to the Trustee would reasonably be unlikely to reach its destination by the time notice by mail is deemed to have been given pursuant to Section 14.3, such notice shall be valid and effective only if delivered at the appropriate address in accordance with Section 14.3.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
