Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System.
4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System.
4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA.
4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code.
4.1.5 The Power Producer shall commission the Project within SCOD.
4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer.
4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.
Offer and Acceptance of Weekend Overtime (a) The Employer is committed to providing reasonable notice to Employees of an offer / cancellation of weekend overtime. To this end, notice will generally be provided prior to the normal meal break on Thursday. Where the Employer is unable to give such notice the Employer may offer I cancel such overtime by notifying affected Employees before the finish time of ordinary hours on Friday.
(b) Overtime will be offered on a work required basis.
(c) Employees who accept an offer of weekend overtime will be obliged to attend. However, Employees may find themselves unable to fulfil their commitment to attend site. Such Employees will notify the Employer before the planned finishing time on Friday.
(d) An Employee may refuse to work weekend overtime if the requirement to do so is plainly unreasonable having regard to:
(i) the hours of work that will be worked by that Employee in the week of the weekend overtime;
(ii) the amount of weekend overtime worked by the Employee within the previous six weeks;
(iii) the Employee’s family responsibilities; and
(iv) any other special circumstances peculiar to the Employee.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:
1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or
2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.
Final Acceptance All Work has been completed and accepted by the County. The Contractor has provided all required close-out documentation and items as required by the Detailed Scope of Work for the specific Job Order, and these items and have accepted and approved by the County
Delivery and Acceptance of the Manuscript The Author shall deliver the Contribution to the Editor (or, if requested by the Publisher, to the Publisher) on or before Delivery Date (the “Delivery Date”) electronically in the Publisher's standard requested format or in such other form as may be agreed in writing with the Publisher. The Author shall retain a duplicate copy of the Contribution. The Contribution shall be in a form acceptable to the Publisher (acting reasonably) and in line with the instructions contained in the Publisher’s guidelines as provided to the Author by the Publisher. The Author shall provide at the same time, or earlier if the Publisher reasonably requests, any editorial, publicity or other information (and in such form or format) reasonably required by the Publisher. The Publisher may exercise such additional quality control of the manuscript as it may decide at its sole discretion including through the use of plagiarism checking systems and/or peer review by internal or external reviewers of its choice. If the Publisher decides at its sole discretion that the final manuscript does not conform in quality, content, structure, level or form to the stated requirements of the Publisher, the Publisher shall be entitled to terminate this Agreement in accordance with the provisions of this Clause. The Author must inform the Publisher at the latest on the Delivery Date if the sequence of the naming of any co-authors entering into this Agreement shall be changed. If there are any changes in the authorship (e.g. a co-author joining or leaving), then the Publisher must be notified by the Author in writing immediately and the Parties will amend this Agreement accordingly. The Publisher shall have no obligation to consider publication under this Agreement in the absence of such agreed amendment. If the Author fails to deliver the Contribution in accordance with the provisions of this Clause above by the Delivery Date (or within any extension period given by the Publisher at its sole discretion) or if the Author (or any co-author) dies or becomes incapacitated or otherwise incapable of performing the Author’s obligations under this Agreement, the Publisher shall be entitled to either: (a) elect to continue to perform this Agreement in accordance with its terms and the Publisher may commission an appropriate and competent person (who, in the case of co-authors having entered into this Agreement, may be a co-author) to complete the Contribution; or (b) terminate this Agreement with immediate effect by written notice to the Author or the Author's successors, in which case all rights granted by the Author to the Publisher under this Agreement shall revert to the Author/Author's successors (subject to the provisions of the Clause "Termination"). The Author agrees, at the request of the Publisher, to execute all documents and do all things reasonably required by the Publisher in order to confer to the Publisher all rights intended to be granted under this Agreement. The Author warrants that the Contribution is original except for any excerpts from other works including pre-published illustrations, tables, animations, text quotations, photographs, diagrams, graphs or maps, and whether reproduced from print or electronic or other sources ("Third Party Material") and that any such Third Party Material is in the public domain (or otherwise unprotected by copyright/other rights) or has been included with written permission from or on behalf of the rights holder (and if requested in a form prescribed or approved by the Publisher) at the Author's expense unless otherwise agreed in writing, or is otherwise used in accordance with applicable law. On request from the Publisher, the Author shall in writing indicate the precise sources of these excerpts and their location in the manuscript. The Author shall also retain the written permissions and make them available to the Publisher on request.
Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.
Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.
