Release of Required Repair Funds Lender shall disburse to Borrower the Required Repair Funds from the Required Repair Account from time to time upon satisfaction by Borrower of each of the following conditions: (i) Borrower shall submit a written request for payment to Lender at least fifteen (15) days prior to the date on which Borrower requests such payment be made and specifies the Required Repairs to be paid, (ii) on the date such request is received by Lender and on the date such payment is to be made, no Default or Event of Default shall exist and remain uncured, (iii) Lender shall have received a certificate from Borrower (A) stating that all Required Repairs at the Property to be funded by the requested disbursement have been completed in good and workmanlike manner and in accordance with all applicable federal, state and local laws, rules and regulations, such certificate to be accompanied by a copy of any license, permit or other approval by any Governmental Authority required to commence and/or complete the Required Repairs, (B) identifying each Person that supplied materials or labor in connection with the Required Repairs performed at the Property to be funded by the requested disbursement under a contract in excess of $50,000, and (C) stating that each Person who has supplied materials or labor in connection with the Required Repairs to be funded by the requested disbursement has been paid in full or will be paid in full upon such disbursement, such certificate to be accompanied by lien waivers or other evidence of payment satisfactory to Lender, (iv) at Lender’s option, a title search for the Property indicating that the Property is free from all liens, claims and other encumbrances not previously approved by Lender, and (v) Lender shall have received such other evidence as Lender shall reasonably request that the Required Repairs at the Property to be funded by the requested disbursement have been completed and are paid for or will be paid upon such disbursement to Borrower. Lender shall not be required to make disbursements from the Required Repair Account with respect to the Property more than once each calendar month and such disbursement shall be made only upon satisfaction of each condition contained in this Section 7.1.2.
Required Repairs Borrower shall perform all of the repairs (on an Individual Property by Individual Property basis) at the applicable Individual Properties, as more particularly set forth on Schedule 5.1.32 hereto (such repairs hereinafter referred to as “Required Repairs”) (i) in compliance with all applicable Legal Requirements, (ii) in a Lien-free, good and workmanlike manner and (iii) prior to the date set forth on Schedule 5.1.32 with respect to such Required Repairs (each such date, a “Required Repair Deadline”). It shall constitute an Event of Default if Borrower does not complete each Required Repair by the applicable Required Repair Deadline, provided that, if Borrower shall have been unable to complete a Required Repair by the applicable Required Repair Deadline, after using commercially reasonable efforts to do so, including, without limitation, if caused by delays due to weather or force majeure, such Required Repair Deadline shall be automatically extended solely as to such Required Repair to permit Borrower to complete such Required Repair so long as Borrower is at all times thereafter diligently and expeditiously proceeding to complete the same. Notwithstanding the foregoing, to the extent any Required Repair is the responsibility of a Tenant pursuant to a Lease, Borrower shall be obligated only to use commercially reasonably efforts to have such Tenant complete such Required Repair on or prior to the Required Repair Deadline.
Withdrawals From Escrow Account Withdrawals from the Escrow Account shall be made by the Seller only (a) to effect timely payments of ground rents, taxes, assessments, premiums for Primary Mortgage Insurance Policies, fire and hazard insurance premiums or other items constituting Escrow Payments for the related Mortgage, (b) to reimburse the Seller for any Servicing Advance made by Seller pursuant to Subsection 11.08 hereof with respect to a related Mortgage Loan, (c) to refund to any Mortgagor any funds found to be in excess of the amounts required under the terms of the related Mortgage Loan, (d) for transfer to the Custodial Account upon default of a Mortgagor or in accordance with the terms of the related Mortgage Loan and if permitted by applicable law, (e) for application to restore or repair of the Mortgaged Property, (f) to pay to the Mortgagor, to the extent required by law, any interest paid on the funds deposited in the Escrow Account, (g) to pay to itself any interest earned on funds deposited in the Escrow Account (and not required to be paid to the Mortgagor), (h) to the extent permitted under the terms of the related Mortgage Note and applicable law, to pay late fees with respect to any Monthly Payment which is received after the applicable grace period, (i) to withdraw suspense payments that are deposited into the Escrow Account, (j) to withdraw any amounts inadvertently deposited in the Escrow Account or (k) to clear and terminate the Escrow Account upon the termination of this Agreement.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Disbursements from Replacement Reserve Account (a) Lender shall make disbursements from the Replacement Reserve Account to pay Borrower only for the costs of the Replacements. Lender shall not be obligated to make disbursements from the Replacement Reserve Account to reimburse Borrower for the costs of routine maintenance to the Property or for costs which are to be reimbursed from the Required Repair Fund (if any).
(b) Lender shall, upon written request from Borrower and satisfaction of the requirements set forth in this Section 7.3.2, disburse to Borrower amounts from the Replacement Reserve Account necessary to pay for the actual approved costs of Replacements or to reimburse Borrower therefor, upon completion of such Replacements (or, upon partial completion in the case of Replacements made pursuant to Section 7.3.2(f)) as determined by Lender. In no event shall Lender be obligated to disburse funds from the Replacement Reserve Account if a Default or an Event of Default exists.
(c) Each request for disbursement from the Replacement Reserve Account shall be in a form specified or approved by Lender and shall specify (i) the specific Replacements for which the disbursement is requested, (ii) the quantity and price of each item purchased, if the Replacement includes the purchase or replacement of specific items, (iii) the price of all materials (grouped by type or category) used in any Replacement other than the purchase or replacement of specific items, and (iv) the cost of all contracted labor or other services applicable to each Replacement for which such request for disbursement is made. With each request Borrower shall certify that all Replacements have been made in accordance with all applicable Legal Requirements of any Governmental Authority having jurisdiction over the Property to which the Replacements are being provided and, unless Lender has agreed to issue joint checks as described below, each request shall include evidence of payment of all such amounts. Each request for disbursement shall include copies of invoices for all items or materials purchased and all contracted labor or services provided. Except as provided in Section 7.3.2(e), each request for disbursement from the Replacement Reserve Account shall be made only after completion of the Replacement for which disbursement is requested. Borrower shall provide Lender evidence of completion satisfactory to Lender in its reasonable judgment.
(d) Borrower shall pay all invoices in connection with the Replacements with respect to which a disbursement is requested prior to submitting such request for disbursement from the Replacement Reserve Account or, at the request of Borrower, Lender will issue joint checks, payable to Borrower and the contractor, supplier, materialman, mechanic, subcontractor or other party to whom payment is due in connection with a Replacement. In the case of payments made by joint check, Lender may require a waiver of lien from each Person receiving payment prior to Lender's disbursement from the Replacement Reserve Account. In addition, as a condition to any disbursement, Lender may require Borrower to obtain lien waivers from each contractor, supplier, materialman, mechanic or subcontractor who receives payment in an amount equal to or greater than $100,000 for completion of its work or delivery of its materials. Any lien waiver delivered hereunder shall conform to the requirements of applicable law and shall cover all work performed and materials supplied (including equipment and fixtures) for the Property by that contractor, supplier, subcontractor, mechanic or materialman through the date covered by the current reimbursement request (or, in the event that payment to such contractor, supplier, subcontractor, mechanic or materialmen is to be made by a joint check, the release of lien shall be effective through the date covered by the previous release of funds request).
(e) If (i) the cost of a Replacement exceeds $100,000, (ii) the contractor performing such Replacement requires periodic payments pursuant to terms of a written contract, and (iii) Lender has approved in writing in advance such periodic payments, a request for reimbursement from the Replacement Reserve Account may be made after completion of a portion of the work under such contract, provided (A) such contract requires payment upon completion of such portion of the work, (B) the materials for which the request is made are on site at the Property and are properly secured or have been installed in the Property, (C) all other conditions in this Agreement for disbursement have been satisfied, (D) funds remaining in the Replacement Reserve Account are, in Lender's judgment, sufficient to complete such Replacement and other Replacements when required, and (E) if required by Lender, each contractor or subcontractor receiving payments under such contract shall provide a waiver of lien with respect to amounts which have been paid to that contractor or subcontractor.
(f) Borrower shall not make a request for disbursement from the Replacement Reserve Account more frequently than once in any calendar month and (except in connection with the final disbursement) the total cost of all Replacements in any request shall not be less than $5,000.00.
Post-Closing Conditions On or before the date specified in this Section 4.3 (unless a longer period is agreed to in writing by the Administrative Agent, in its reasonable discretion), the Borrower shall satisfy each of the following items specified in the subsections below:
Release of Escrow Funds The Escrow Funds shall be paid by the Escrow Agent in accordance with the following:
(a) In the event that the Company advises the Escrow Agent in writing that the Offering has been terminated (the “Termination Notice”), the Escrow Agent shall promptly return the funds paid by each Investor to such Investor without interest or offset.
(b) At each Closing, the Company and the Placement Agent shall provide the Escrow Agent with written instructions regarding the disbursement of the Escrow Funds in accordance with Exhibit A attached hereto and made a part hereof and signed by the Company and the Placement Agent (the “Disbursement Instructions”).
(c) If by 5:00 P.M. Eastern time on the Final Termination Date, the Escrow Agent has not received written Disbursement Instructions from the Company and Placement Agent regarding the disbursement of the Escrow Funds in the Escrow Account, if any, then the Escrow Agent shall promptly return such Escrow Funds, if any, to the Investors without interest or offset. The Escrow Funds returned to the Investors shall be free and clear of any and all claims of the Escrow Agent.
(d) The Escrow Agent shall not be required to pay any uncollected funds or any funds that are not available for withdrawal.
(e) The Placement Agent or the Company will provide the Escrow Agent with the payment instructions for each Investor, to whom the funds should be returned in accordance with this section.
(f) In the event that Escrow Agent makes any payment to any other party pursuant to this Escrow Agreement and for any reason such payment (or any portion thereof) is required to be returned to the Escrow Account or another party or is subsequently invalidated, declared to be fraudulent or preferential, set aside and/or required to be repaid to a receiver, trustee or other party under any bankruptcy or insolvency law, other federal or state law, common law or equitable doctrine, then the recipient party shall repay to the Escrow Agent upon written request the amount so paid to it.
(g) The Escrow Agent shall, in its sole discretion, comply with judgments or orders issued or process entered by any court with respect to the Escrow Amount, including without limitation any attachment, levy or garnishment, without any obligation to determine such court's jurisdiction in the matter and in accordance with its normal business practices. If the Escrow Agent complies with any such judgment, order or process, then it shall not be liable to any of the Parties or any other person by reason of such compliance, regardless of the final disposition of any such judgment, order or process.
(h) Each Party understands and agrees that Escrow Agent shall have no obligation or duty to act upon a written direction delivered to Escrow Agent for the disbursement of all or part of the Escrow Amount under this Agreement (a “Written Direction”) if such Written Direction is not
(i) in writing,
(ii) signed by representatives of both Parties listed in Schedule II to this Agreement, in each case, each such individual an “Authorized Representative” of such Party), and
(iii) delivered to, and able to be authenticated by, Escrow Agent in accordance with Section 1.4 below.
(i) Upon request by any Party, the Escrow Agent set up each Party with on-line access to the account(s) established pursuant to this Agreement, which each Party can use to view and verify transaction on such account(s).
(j) A Party may specify in a Written Direction whether such Escrow Amount shall be disbursed by way of wire transfer or check. If the written notice for the disbursement of funds does not so specify the disbursement means, Escrow Agent may disburse the Escrow Amount by wire transfer.
Establishment of Escrow Accounts; Deposits in Escrow Accounts The Company shall segregate and hold all funds collected and received pursuant to each Mortgage Loan which constitute Escrow Payments separate and apart from any of its own funds and general assets and shall establish and maintain one or more Escrow Accounts. The Escrow Account shall be an Eligible Account. Funds deposited in each Escrow Account shall at all times be insured in a manner to provide maximum insurance under the insurance limitations of the FDIC, or must be invested in Permitted Investments. Funds deposited in the Escrow Account may be drawn on by the Company in accordance with Section 4.07. The creation of any Escrow Account shall be evidenced by a letter agreement in the form shown in Exhibit C. The original of such letter agreement shall be furnished to the Purchaser on the Closing Date, and upon request to any subsequent purchaser. The Company shall deposit in the Escrow Account or Accounts on a daily basis, and retain therein:
(i) all Escrow Payments collected on account of the Mortgage Loans, for the purpose of effecting timely payment of any such items as required under the terms of this Agreement;
(ii) all Insurance Proceeds which are to be applied to the restoration or repair of any Mortgaged Property; and
(iii) all Servicing Advances for Mortgagors whose Escrow Payments are insufficient to cover escrow disbursements. The Company shall make withdrawals from the Escrow Account only to effect such payments as are required under this Agreement, and for such other purposes as shall be as set forth or in accordance with Section 4.07. The Company shall be entitled to retain any interest paid on funds deposited in the Escrow Account by the depository institution other than interest on escrowed funds required by law to be paid to the Mortgagor and, to the extent required by law, the Company shall pay interest on escrowed funds to the Mortgagor notwithstanding that the Escrow Account is non-interest bearing or that interest paid thereon is insufficient for such purposes. The Purchaser shall not be responsible for any losses suffered with respect to investment of funds in the Escrow Account.
Disbursements from the Escrow Account a. At such time as Escrow Agent has collected and deposited instruments of payment in the total amount of the Advance and has received such Common Stock via D.W.A.C from the Company which are to be issued to the Investor pursuant to the Standby Equity Distribution Agreement, the Escrow Agent shall notify the Company and the Investor. The Escrow Agent will continue to hold such funds until the Investor and Company execute and deliver a Joint Written Direction directing the Escrow Agent to disburse the Escrow Funds pursuant to Joint Written Direction at which time the Escrow Agent shall wire the Escrow Funds to the Company. In disbursing such funds, Escrow Agent is authorized to rely upon such Joint Written Direction from Company and may accept any signatory from the Company listed on the signature page to this Agreement and any signature from the Investor that Escrow Agent already has on file. Simultaneous with delivery of the executed Joint Written Direction to the Escrow Agent the Investor and Company shall execute and deliver a Common Stock Joint Written Direction to the Escrow Agent directing the Escrow Agent to release via D.W.A.C to the Investor the shares of the Company's Common Stock. In releasing such shares of Common Stock the Escrow Agent is authorized to rely upon such Common Stock Joint Written Direction from Company and may accept any signatory from the Company listed on the signature page to this Agreement and any signature from the Escrow Agent has on file. In the event the Escrow Agent does not receive the amount of the Advance from the Investor or the shares of Common Stock to be purchased by the Investor from the Company, the Escrow Agent shall notify the Company and the Investor.
