Remedies for Builder’s Default Sample Clauses

Remedies for Builder’s Default. 1. In the event that any one or more of the events of default specified herein shall have occurred, the Buyer, if it so elects, may terminate Builder’s performance hereunder, provided Buyer shall have given Builder a reasonable opportunity to cure such default. The Buyer may, subject to Subparagraph 2 below. a. proceed to have the Tug completed, and for such purposes may take possession of the Tug and remove it from the Shipyard, and in so doing invoke the security devices set out in Article XXIV. If Buyer exercises this option, Builder shall be liable for any costs based on market prices required for the completion of the Tug less any costs saved by its completion in a yard other than Builder’s or b. if Builder is in default because a Tug fails to meet the performance criteria contained in this Contract, demand that the Tug be sold, in which case the Builder shall tender the proceeds of sale, and shall pay the difference between the proceeds of the sale and the cost of constructing a replacement Tug, up to the liability cap set forth in this Contract. 2. If Buyer terminates this Contract because of Builder’s default, Builder shall stop work, and may not recover any further payments until the work has been completed by Buyer and only if the unpaid portion of the Contract Price exceeds all of the reasonable costs (including litigation costs, reasonable attorney fees and liquidated damages) incurred by Buyer in [****] Confidential Treatment enforcing this Contract and completing the work (“Buyer’s Expense”). If the unpaid portion of the Contract Price exceeds Buyer’s Expense, Buyer will pay the excess amount to Builder. If Buyer’s Expense exceeds the unpaid balance of the Contract Price, Builder shall pay the difference to Buyer, subject to the limitations contained in Subparagraph 4. 3. In the event that Builder files for protection under the bankruptcy laws of the United States while performing work on a Maritrans vessel, it specifically agrees to either accept or reject this contract within the later of seven (7) working days of the bankruptcy filing, or the minimum period permitted under the bankruptcy laws. In the event Builder rejects the contract entered into herein, it agrees to immediately return all property owned by Maritrans in its possession. Said property includes, but is not limited to, the Vessel, as well as all complements, accoutrements, appurtenances, equipment, and material prepared for use in said Vessel.
Sample 1
AutoNDA by SimpleDocs

Related to Remedies for Builder’s Default

  • Remedies for Default (a) Enterprise Services’ rights to suspend and terminate Contractor’s rights under this Master Contract are in addition to all other available remedies. (b) In the event of termination for default, Enterprise Services may exercise any remedy provided by law including, without limitation, the right to procure for all Purchasers replacement goods and/or services. In such event, Contractor shall be liable to Enterprise Services for damages as authorized by law including, but not limited to, any price difference between the Master Contract price and the replacement or cover price as well as any administrative and/or transaction costs directly related to such replacement procurement – e.g., the cost of the competitive procurement.

  • Breach and Remedies for Breach The benefits associated with Sector membership will only accrue to the Members if each of them strictly complies with this Agreement. Each Member will make significant operational and financial commitments based on this Agreement, and any Member’s failure to fulfill any of its obligations under this Agreement could have significant adverse consequences for some or all other Members. Any failure by a Member to fulfill any of its obligations under this Agreement shall constitute a breach of this Agreement. Each Member shall be bound by the procedures set forth in this Section for determining whether a Member has breached this Agreement. The Sector shall be entitled to the remedies set forth in this Section if a Member is determined by the Sector to have breached this Agreement. Each Member shall take all actions and execute all documents the Manager deems necessary or convenient to give effect to the provisions of this Section.

  • Rights and Remedies Upon Breach If Executive breaches or threatens to commit a breach of any of the provisions of this Section 5 (the “Restrictive Covenants”), the Company shall have the following rights and remedies, each of which rights and remedies shall be independent of the other and severally enforceable, and all of which rights and remedies shall be in addition to, and not in lieu of, any other rights and remedies available to the Company under law or in equity:

  • Remedies for Events of Default If an Event of Default, as defined in the Indenture, occurs and is continuing, the Trustee or the Holders of not less than 25% in principal amount of the Notes then outstanding may declare all the Notes to be immediately due and payable. If a bankruptcy or insolvency default with respect to the Company or any of its Significant Subsidiaries occurs and is continuing, the Notes automatically become immediately due and payable. Holders may not enforce the Indenture or the Notes except as provided in the Indenture. The Trustee may require indemnity satisfactory to it before it enforces the Indenture or the Notes. Subject to certain limitations, Holders of at least a majority in principal amount of the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

  • Remedies of the Bank 4.01. The Additional Event of Suspension consists of the following, namely, that a situation has arisen which shall make it improbable that the Program, or a significant part of it, will be carried out.

  • Remedies Upon Breach I understand that the restrictions contained in this Agreement are necessary for the protection of the business and goodwill of the Company and I consider them to be reasonable for such purpose. Any breach of this Agreement is likely to cause the Company substantial and irrevocable damage and therefore, in the event of such breach, the Company, in addition to such other remedies which may be available, will be entitled to specific performance and other injunctive relief.

  • Tenant’s Remedies/Limitation of Liability Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.

  • Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both CMHA and the contractor to communicate with each other in as clear and complete a manner as possible. If at any time during the term of this contract CMHA or the contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that CMHA has the right to issue unilateral addendums to this contract, but the contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, CMHA shall retain the right to, if conditions warrant, require the contractor to respond in a shorter period of time). Further, CMHA shall, at a minimum, employ the following steps in dealing with the contractor as to any performance issues: 20.16.1.1. If the contractor is in material breach of the contract, CMHA may promptly invoke the termination clause detailed within Section No. 3, form HUD-5370-C, General Conditions for Non-Construction Contracts, Section I—(With or without Maintenance Work), which is attached hereto, and terminate the contract for cause. Such termination must be delivered to the contractor in writing and shall fully detail all pertinent issues pertaining to the cause of and justification for the termination. 20.16.1.2. Prior to termination, CMHA may choose to warn 20.16.1.3. After termination, if the contractor does not agree with CMHA’s justification for the termination, the contractor shall have 10 days to dispute, in writing, such action; if he/she does not do so within the 10-day period, he/she shall have no recourse but to accept and agree with CMHA’s position on the issue. The written protest must detail all pertinent information pertaining to the dispute, including justification detailing CMHA’s alleged incorrect action(s). 20.16.1.4. The response to any protest received shall be conducted in accordance with Section No. 4.0 of this document. 20.16.1.5. It is CMHA’s policy to resolve all contractual issues informally and without litigation. Disputes will not be referred to HUD unless all administrative remedies have been exhausted. When appropriate, a mediator may be used to help resolve differences. 20.16.1.6. For contracts of $100,000 or less, the bidder/contractor may request to meet with the Procurement Officer. 20.16.1.7. All claims by a contractor relating to performance of a contract shall be submitted in writing to the Procurement Officer or designee for a written decision. The contractor may request a conference on the claim. The Procurement Officer’s decision shall inform the contractor of its appeal rights to the next higher level of authority in CMHA. Contractor claims shall be governed by the Changes clause in the form HUD-5370-C.

  • Rights and Remedies Upon Default Upon occurrence of any Event of Default and at any time thereafter, the Secured Party shall have the right to exercise all of the remedies conferred hereunder and under the Notes, and the Secured Party shall have all the rights and remedies of a secured party under the UCC and/or any other applicable law (including the Uniform Commercial Code of any jurisdiction in which any Collateral is then located). Without limitation, the Secured Party shall have the following rights and powers: (a) The Secured Party shall have the right to take possession of the Collateral and, for that purpose, enter, with the aid and assistance of any person, any premises where the Collateral, or any part thereof, is or may be placed and remove the same, and the Company shall assemble the Collateral and make it available to the Secured Party at places which the Secured Party shall reasonably select, whether at the Company's premises or elsewhere, and make available to the Secured Party, without rent, all of the Company's respective premises and facilities for the purpose of the Secured Party taking possession of, removing or putting the Collateral in saleable or disposable form. (b) The Secured Party shall have the right to operate the business of the Company using the Collateral and shall have the right to assign, sell, lease or otherwise dispose of and deliver all or any part of the Collateral, at public or private sale or otherwise, either with or without special conditions or stipulations, for cash or on credit or for future delivery, in such parcel or parcels and at such time or times and at such place or places, and upon such terms and conditions as the Secured Party may deem commercially reasonable, all without (except as shall be required by applicable statute and cannot be waived) advertisement or demand upon or notice to the Company or right of redemption of the Company, which are hereby expressly waived. Upon each such sale, lease, assignment or other transfer of Collateral, the Secured Party may, unless prohibited by applicable law which cannot be waived, purchase all or any part of the Collateral being sold, free from and discharged of all trusts, claims, right of redemption and equities of the Company, which are hereby waived and released.

  • REMEDIES OF THE PARTIES a. If Buyers (a) fail to make the payments aforesaid, or any part thereof, as same become due; or (b) fail to pay the taxes or special assessments or charges, or any part thereof, levied upon said property, or assessed against it, by any taxing body before any of such items become delinquent; or (c) fail to keep the property insured; or (d) fail to keep it in reasonable repair as herein required; or (e) fail to perform any of the agreements as herein made or required; then Sellers, in addition to any and all other legal and equitable remedies which they may have, at their option, may proceed to forfeit and cancel this contract as provided by law (Chapter 656 Code of Iowa). Upon completion of such forfeiture Buyers shall have no right of reclamation or compensation for money paid, or improvements made; but such payments and/or improvements if any shall be retained and kept by Sellers as compensation for the use of said property, and/or as liquidated damages for breach of this contract ; and upon completion of such forfeiture, if the Buyers, or any other person or persons shall be in possession of said real estate or any part thereof, such party or parties in possession shall at once peacefully remove therefrom, or failing to do so may be treated as tenants holding over, unlawfully after the expiration of lease, and may accordingly be ousted and removed as such as provided by law. b. If Buyers fail to timely perform this contract, Sellers, at their option, may elect to declare the entire balance immediately due and payable after such notice, if any, as may be required by Chapter 654, The Code. Thereafter this contract may be foreclosed in equity and the court may appoint a receiver to take immediate possession of the property and of the revenues and income accruing therefrom and to rent or cultivate the same as the receiver may deem best for the interest of all parties concerned, and such receiver shall be liable to account to Buyers only for the net profits, after application of rents, issues and profits from the costs and expenses of the receivership and foreclosure and upon the contract obligation. It is agreed that if this contract covers less than ten (10) acres of land, and in the event of the foreclosure of this contract and sale of the property by sheriff's sale in such foreclosure proceedings, the time of one year for redemption from said sale provided by the statutes of the State of Iowa shall be reduced to six (6) months provided the Sellers, in such action file an election to waive any deficiency judgment against Buyers which may arise out of the foreclosure proceedings; all to be consistent with the provisions of Chapter 628 of the Iowa Code. If the redemption period is so reduced, for the first three (3) months after sale such right of redemption shall be exclusive to the Buyers, and the time periods in Sections 628.5, 628.15 and 628.16 of the Iowa Code shall be reduced to four (4) months. (1) The real estate is less than ten (10) acres in size; (2) the Court finds affirmatively that the said real estate has been abandoned by the owners and those persons personally liable under this contract at the time of such foreclosure; and (3) Sellers in such action file an election to waive any deficiency judgment against Buyers or their successor in interest in such action. If the redemption period is so reduced, Buyers or their successors in interest or the owner shall have the exclusive right to redeem for the first thirty (30) days after such sale, and the time provided for redemption by creditors as provided in Sections 628.5, 628.15 and 628.16 of the Iowa Code shall be reduced to forty (40) days. Entry of appearance by pleading or docket entry by or on behalf of Buyers shall be presumption that the property is not abandoned. Any such redemption period shall be consistent with all of the provisions of Chapter 628 of the Iowa Code. This paragraph shall not be construed to limit or otherwise affect any other redemption provisions contained in Chapter 628 of the Iowa Code. Upon completion of such forfeiture Buyers shall have no right of reclamation or compensation for money paid, or improvements made; but such payments and for improvements if any shall be retained and kept by Sellers as compensation for the use of said property, and/or as liquidated damages for breach of this contract; and upon completion of such forfeiture, if Buyers, or any other person or persons shall be in possession of said real estate or any part thereof, such party or parties in possession shall at once peacefully remove therefrom, or failing to do so may be treated as tenants holding over, unlawfully after the expiration of a lease, and may accordingly be ousted and removed as such as provided by law. c. If Sellers fail to timely perform their obligations under this contract, Buyers shall have the right to terminate this contract and have all payments made returned to them. d. Buyers and Sellers are also entitled to utilize any and all other remedies or actions at law or in equity available to them. e. In any action or proceeding relating to this contract the successful party shall be entitled to receive reasonable attorney's fees and costs as permitted by law.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!