Integration Clause Except for documents and instruments specifically referenced herein, this Agreement constitutes the entire agreement between Bank and Borrower regarding the Loan and all prior communications verbal or written between Borrower and Bank shall be of no further effect or evidentiary value.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Access to Work Locations Reasonable access to employee work locations shall be granted officers of the Association and their officially designated representatives for the purpose of processing grievances or contacting members of the Association concerning business within the scope of representation. Such officers or representatives shall not enter any work location without the consent of the City Manager. Access shall be restricted so as not to interfere with the normal operations of the department or with established safety or security requirements. Solicitation of membership and activities concerned with the internal management of the Association, such as collecting dues, holding membership meetings, campaigning for office, conducting elections and distributing literature, shall not be conducted during working hours.
APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.
AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)
Contractor Certification Clauses Contractor represents and warrants that the following statements are true. During the term of the Agreement, Contractor shall not take an action, or omit to perform any act, that results in a representation and warranty becoming untrue. Contractor shall promptly notify the Judicial Council if any representation and warranty becomes untrue. A. No Gratuities. Contractor has not directly or indirectly offered or given any gratuities (in the form of entertainment, gifts, or otherwise) to any Judicial Council personnel with a view toward securing this Agreement or securing favorable treatment with respect to any determinations concerning the performance of this Agreement.
NO STRIKE CLAUSE During the life of this Agreement the VSEA and employees covered by this Agreement acknowledge their statutory obligations in relation to 3 VSA 903(b) and agree to be bound thereby.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
CONTRACT CLAUSES A SOLICITATION/CONTRACT FORM 1 I CONTRACT CLAUSES 58 B SUPPLIES OR SERVICES AND PRICES/COSTS 2 PART III - LIST OF DOCUMENTS, EXHIBITS & ATTACHMENTS C DESCRIPTION/SPECS./WORK STATEMENT 25 J LIST OF ATTACHMENTS 74 D PACKAGING AND MARKING 26 PART IV - REPRESENTATIONS AND INSTRUCTIONS E INSPECTION AND ACCEPTANCE 27 K REPRESENTATIONS, CERTIFICATIONS OTHER STATEMENTS OF OFFERORS F DELIVERIES OR PERFORMANCE 29 G CONTRACT ADMINISTRATION DATA 32 L INSTRS., CONDS., AND NOTICES TO H SPECIAL CONTRACT REQUIREMENTS 34 M EVALUATION FACTORS FOR AWARD
Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of: (a) A member of a safety committee; or (b) A person designated by a safety committee; or (c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.
