Request for Excusable Delay Credit Sample Clauses

Request for Excusable Delay Credit. CONSULTANT shall, within five (5) calendar days of the beginning of any excusable delay (unless the DISTRICT grants in writing a further period of time to file such notice before the date of final payment under the Agreement), notify the DISTRICT in writing of the causes of delay. The DISTRICT will ascertain the facts and the extent of the delay, and grant an extension of time for completing the services when, in its sole judgment, the findings of fact justify such an extension. The DISTRICT'S findings of fact thereon shall be final and conclusive on the parties. Extensions of time shall apply only to that portion of the services affected by the delay and shall not apply to other portions of the services not so affected. CONSULTANT’s sole remedy for extensions of time shall be an extension of the performance time at no cost to the DISTRICT. Should CONSULTANT make an application for an extension of time, CONSULTANT shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Request for Excusable Delay Credit. The Architect shall, within ten (10) calendar days of the beginning of any excusable delay, notify the DISTRICT in writing of the causes of delay. DISTRICT will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The DISTRICT's findings of fact thereon shall be final and conclusive on the parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Architect for extensions of time shall be an extension of the performance time at no cost to the DISTRICT. If Additional Services are required as a result of an excusable delay, the parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Architect make an application for an extension of time, Architect shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
Sample 1Sample 2
Request for Excusable Delay Credit. The Designer shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Designer for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Designer make an application for an extension of time, Designer shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
Sample 1
Request for Excusable Delay Credit. The Architect shall, within ten (10) calendar days of the beginning of any excusable delay, notify the District in writing of the causes of delay. District will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its reasonable judgment, the findings of fact justify such an extension. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Architect for extensions of time shall be an extension of the performance time at no cost to the District. If Additional Services are required as a result of an excusable delay, the parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Architect make an application for an extension of time, Architect shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
Sample 1
Request for Excusable Delay Credit. Architect shall, within ten (10) calendar days of the beginning of any excusable delay (unless District grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement), notify District in writing of the causes of delay. District will ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. District’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Architect for extensions of time shall be an extension of the performance time at no cost to District. If additional Services are required as a result of an excusable delay, the parties shall mutually agree thereto pursuant to the Additional Architect Services provision in Subsection 6 below. Should Architect make an application for an extension of time, Architect shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
Sample 1
Request for Excusable Delay Credit. The Architect shall, within fifteen
Sample 1
Request for Excusable Delay Credit. The Designer shall, within fifteen
Sample 1
AutoNDA by SimpleDocs

Related to Request for Excusable Delay Credit

  • Request for Extension Upon request, the Department may extend the time allowed for both a response to the Letter of Concern and a Corrective Action Plan depending upon the nature of the deficiency. The Provider shall request an extension of time in writing from the Department’s designated representative. The written request shall contain a justification and proposed extension period.

  • Vacation Leave Accrual Rate Schedule Full Years of Service Hours Per Year During the first year of current continuous employment Ninety-six (96) During the second year of current continuous employment One hundred four (104) During the third and fourth years of current continuous employment One hundred twelve (112) During the fifth, sixth, and seventh years of total employment One hundred twenty (120) During the eighth, ninth, and tenth years of total employment One hundred twenty-eight (128) During the eleventh year of total employment One hundred thirty-six (136) During the twelfth year of total employment One hundred forty-four (144) During the thirteenth year of total employment One hundred fifty-two (152) During the fourteenth year of total employment One hundred sixty (160) During the fifteenth year of total employment One hundred sixty-eight (168) During the sixteenth year of total employment and thereafter One hundred seventy-six (176)

  • Accrual Rate of Sick Leave With Pay Credits Full-time employees shall accrue eight (8) hours of sick leave with pay credits for each full month worked. Employees who work less than the full month but at least thirty-two (32) hours during the month shall accrue sick leave with pay on a pro rata basis for the month.

  • Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:

  • Borrowing of Unearned Vacation Credits With the approval of the Employer, an Employee who has been employed for a period of five (5) or more years may be granted five (5) days from the vacation leave of the next subsequent year.

  • TERM, TERMINATION & SUSPENSION The Company may terminate this Agreement with You at any time for any reason, with or without cause. The Company specifically reserves the right to terminate this Agreement if You violate any of the terms outlined herein, including, but not limited to, violating the intellectual property rights of the Company or a third party, failing to comply with applicable laws or other legal obligations, and/or publishing or distributing illegal material. If You have registered for an account with Us, You may also terminate this Agreement at any time by contacting Us and requesting termination. At the termination of this Agreement, any provisions that would be expected to survive termination by their nature shall remain in full force and effect.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!