MOTION FOR PRELIMINARY APPROVAL The Parties agree to jointly prepare and file a motion for preliminary approval (“Motion for Preliminary Approval”) that complies with the Court’s current checklist for Preliminary Approvals.
Draw Request At such time as the Borrower shall desire to obtain, subject to the other requirements hereof, a disbursement of any portion of the proceeds of the Loan, the Borrower shall complete, execute and deliver to the City a properly completed draw request in a form designated by the City, together with the General Contractor's Payment Request which shall have been approved by the City's Inspector and by such other documents as the City may request ("Draw Request"), all in such form as the City may require from time to time. No failure or delay on the part of the City to require any such documents or information shall operate in any way so as to waive the City's rights to require all such documents and information at a later time. Draw requests will occur no more often than monthly, only with proper certification of completion from the Architect, and with the xxxxx 0% retainage being paid only after receipt of a Certificate of Occupancy and Release of Liens. All draw disbursements shall be made in accordance with the Escrow and Disbursing Agreement.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Drawings and Specifications 9.1 A complete list of all Drawings that form a part of the Contract Documents are to be found as an index on the Drawings themselves, and/or may be provided to Developer and/or in the Table of Contents. 9.2 Materials or Work described in words that so applied have a well-known technical or trade meaning shall be deemed to refer to recognized standards, unless noted otherwise. 9.3 Trade Name or Trade Term It is not the intention of the Contract Documents to go into detailed descriptions of any materials and/or methods commonly known to the trade under “trade name” or “trade term.” The mere mention or notation of “trade name” or “trade term” shall be considered a sufficient notice to Developer that it will be required to complete the work so named, complete, finished, and operable, with all its appurtenances, according to the best practices of the trade. 9.4 The naming of any material and/or equipment shall mean furnishing and installing of same, including all incidental and accessory items thereto and/or labor therefor, as per best practices of the trade(s) involved, unless specifically noted otherwise. 9.5 Contract Documents are complementary, and what is called for by one shall be binding as if called for by all. As such, Drawings and Specifications are intended to be fully cooperative and to agree. However, if Developer observes that Drawings and Specifications are in conflict with the Contract Documents, Developer shall promptly notify District and Architect in writing, and any necessary changes shall be made as provided in the Contract Documents. 9.6 Figured dimensions shall be followed in preference to scaled dimensions, and Developer shall make all additional measurements necessary for the work and shall be responsible for their accuracy. Before ordering any material or doing any work, each Developer shall verify all measurements at the building and shall be responsible for the correctness of same. 9.7 Should any question arise concerning the intent or meaning of the Contract Documents, including the Plans and Specifications, the question shall be submitted to the District for interpretation. If a conflict exists in the Contract Documents, these Construction Provisions shall control over the Facilities Lease, which shall control over the Site Lease, which shall control over Division 1 Documents, which shall control over Division 2 through Division 49 documents, which shall control over figured dimensions, which shall control over large-scale drawings, which shall control over small-scale drawings. In no case shall a document calling for lower quality and/or quantity of material or workmanship control. However, in the case of discrepancy or ambiguity solely between and among the Drawings and Specifications, the discrepancy or ambiguity shall be resolved in favor of the interpretation that will provide District with the functionally complete and operable Project described in the Drawings and Specifications. 9.8 Drawings and Specifications are intended to comply with all laws, ordinances, rules, and regulations of constituted authorities having jurisdiction, and where referred to in the Contract Documents, the laws, ordinances, rules, and regulations shall be considered as a part of the Contract Documents within the limits specified. 9.9 As required by Section 4-317(c), Part 1, Title 24, CCR: “Should any existing conditions such as deterioration or non-complying construction be discovered which is not covered by the DSA-approved documents wherein the finished work will not comply with Title 24, California Code of Regulations, a construction change document, or a separate set of plans and specifications, detailing and specifying the required repair work shall be submitted to and approved by DSA before proceeding with the repair work.”
Proper Instructions and Special Instructions “Proper Instructions,” which may also be standing instructions, as such term is used throughout this Agreement shall mean instructions received by the Custodian from a Fund, a Fund’s duly authorized investment manager or investment adviser, or a person or entity duly authorized by either of them. Such instructions may be in writing signed by the authorized person or persons or may be in a tested communication or in a communication utilizing access codes effected between electro-mechanical or electronic devices or may be by such other means and utilizing such intermediary systems and utilities as may be agreed from time to time by the Custodian and the person(s) or entity giving such instruction, provided that the Fund has followed any security procedures agreed to from time to time by the applicable Fund and the Custodian including, but not limited to, the security procedures selected by the Fund via the form of Funds Transfer Addendum hereto, the terms of which are hereby agreed to. Oral instructions will be considered Proper Instructions if the Custodian reasonably believes them to have been given by a person authorized to provide such instructions with respect to the transaction involved; the Fund shall cause all oral instructions to be confirmed in writing. For purposes of this Section, Proper Instructions shall include instructions received by the Custodian pursuant to any multi-party agreement which requires a segregated asset account in accordance with Section 2.9 hereof.
Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.
Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
