Applications for Payment 9.3.1 At least ten days before the date for each progress payment established in the State- Contractor Agreement, the Contractor shall submit to the Architect an itemized Application for Payment, notarized if required, supported by such data substantiating the Contractor's right to payment as the State or the Architect may require. The application for payment must, at a minimum, reflect retainage and the required waivers of lien and any other support documentation enumerated elsewhere in the Contract Documents.
9.3.2 Unless otherwise provided in the Contract Documents, payments will be made on account of materials or equipment not incorporated in the Work but delivered and suitably stored at the site and, if approved in advance by the State, payments may similarly be made for materials or equipment suitably stored at some other location agreed upon in writing. Payments for materials or equipment stored on or off the site shall be conditioned upon submission by the Contractor of bills of sale or such other procedures satisfactory to the State to establish the State's title to such materials or equipment or otherwise protect the State's interest, including applicable insurance and transportation to the site for those materials and equipment stored off the site.
9.3.3 The Contractor warrants that title to all Work, materials and equipment covered by an Application for Payment will pass to the State either by incorporation in the construction or upon the receipt of payment by the Contractor, whichever occurs first, free and clear of all liens, claims, security interests or encumbrances, hereinafter referred to in this Article 9 as "liens"; and that no Work, materials or equipment covered by an Application for Payment will have been acquired by the Contractor, or by any other person performing Work at the site or furnishing materials and equipment for the Project, subject to an agreement under which an interest therein or an encumbrance thereon is retained by the seller or otherwise imposed by the Contractor or such other person.
Provisions for Payment The Securities shall be issuable as registered Securities and in the denominations of one thousand U.S. dollars ($1,000) or any integral multiple thereof, subject to Section 2.01(a)(13). The Securities of a particular series shall bear interest payable on the dates and at the rate specified with respect to that series. Subject to Section 2.01(a)(23), the principal of and the interest on the Securities of any series, as well as any premium thereon in case of redemption or repurchase thereof prior to maturity, and any cash amount due upon conversion or exchange thereof, shall be payable in the coin or currency of the United States of America that at the time is legal tender for public and private debt, at the office or agency of the Company maintained for that purpose. Each Security shall be dated the date of its authentication. Interest on the Securities shall be computed on the basis of a 360-day year composed of twelve 30-day months. The interest installment on any Security that is payable, and is punctually paid or duly provided for, on any Interest Payment Date for Securities of that series shall be paid to the Person in whose name said Security (or one or more Predecessor Securities) is registered at the close of business on the regular record date for such interest installment. In the event that any Security of a particular series or portion thereof is called for redemption and the redemption date is subsequent to a regular record date with respect to any Interest Payment Date and prior to such Interest Payment Date, interest on such Security will be paid upon presentation and surrender of such Security as provided in Section 3.03. Any interest on any Security that is payable, but is not punctually paid or duly provided for, on any Interest Payment Date for Securities of the same series (herein called “Defaulted Interest”) shall forthwith cease to be payable to the registered holder on the relevant regular record date by virtue of having been such holder; and such Defaulted Interest shall be paid by the Company, at its election, as provided in clause (1) or clause (2) below:
Progress Payments 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents.
Solicitations for Subcontracts, Including Procurements of Materials and Equipment In all solicitations either by competitive bidding or negotiation made by the Engineer for work to be performed under a subcontract, including procurements of materials or leases of equipment, each potential subcontractor or supplier shall be notified by the Engineer of the Engineer's obligations under this contract and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin.
Scope of Application Except as otherwise provided in this Agreement, the dispute settlement provisions of this Chapter shall apply with respect to the settlement of all disputes between the Parties regarding the interpretation or application of this Agreement, whenever a Party considers that the other Party has failed to carry out its obligations under this Agreement.
Motions for Directions (1) Class Counsel or the Settling Defendants may apply to the Ontario Court and/or such other courts as may be required by the Courts for directions in respect of the interpretation, implementation and administration of this Settlement Agreement. Unless the Courts order otherwise, motions for directions that do not relate specifically to the matters affecting the Quebec Action shall be determined by the Ontario Court.
(2) All motions contemplated by this Settlement Agreement shall be on notice to the Parties.
Solicitations for Subcontracts, Including Procurement of Materials and Equipment In all solicitations either by competitive bidding or negotiation made by the Local Government for work to be performed under a subcontract, including procurement of materials or leases of equipment, each potential subcontractor or supplier will be notified by the Local Government of the Local Government’s obligations under this Agreement and the Acts and Regulations relative to Nondiscrimination on the grounds of race, color, or national origin.
PUBLIC RECORDS COMPLIANCE (APPLICABLE FOR SERVICE CONTRACTS Orange County is a public agency subject to Chapter 119, Florida Statutes. The Contractor agrees to comply with Florida’s Public Records Law. Specifically, the Contractor shall:
1. Keep and maintain public records required by Orange County to perform the service.
2. Upon request from Orange County’s custodian of public records, provide Orange County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from the public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to Orange County.
4. Upon completion of the contract, Contractor agrees to transfer at no cost to Orange County all public records in possession of the Contractor or keep and maintain public records required by Orange County to perform the service. If the Contractor transfers all public record to Orange County upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to Orange County, upon request from Orange County’s custodian of public records, in a format that is compatible with the information technology systems of Orange County.
5. A Contractor who fails to provide the public records to Orange County within a reasonable time may be subject to penalties under section 119.10, Florida Statutes.
6. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR’S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT : Procurement Public Records Liaison
Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.
Progress Payments; Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor’s Applications for Payment on or about the first day of each month during performance of the Work as provided in Paragraph 6.02.A.1 below, provided that such Applications for Payment have been submitted in a timely manner and otherwise meet the requirements of the Contract. All such payments will be measured by the Schedule of Values established as provided in the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no Schedule of Values, as provided elsewhere in the Contract.
1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below but, in each case, less the aggregate of payments previously made and less such amounts as Owner may withhold, including but not limited to liquidated damages, in accordance with the Contract
a. 95 percent of Work completed (with the balance being retainage). If the Work has been 50 percent completed as determined by Engineer, and if the character and progress of the Work have been satisfactory to Owner and Engineer, then as long as the character and progress of the Work remain satisfactory to Owner and Engineer, there will be no additional retainage; and
