Rights and Responsibilities of Institution and Tx HHS
Rights and Responsibilities of Institution and Tx HHS Sample Clauses
Related to Rights and Responsibilities of Institution and Tx HHS
Responsibilities of Both Parties 6.1 The CLEC providing the circuit between CLEC’s office and SBC-12STATE’s office shall make such circuits available for use in connection with the DA services covered herein. When the total traffic exceeds the capability of the existing circuits, additional circuits will be provided by the CLEC. 6.2 Where applicable, if additional ADAX cards and ASN Routers (with sync and token ring cards) are necessary, they will be provided by SBC-12STATE, and CLEC will reimburse SBC-12STATE for the cost, plus Engineering, Furnish and Installation.
RESPONSIBILITIES OF THE UNIVERSITY The UNIVERSITY shall designate in writing a faculty member to coordinate with a designee of the FIELDWORK SITE.
RESPONSIBILITIES OF THE STATE 3.2.1 The State will identify a Project Manager for the Project. The Project Manager will be the sole point of contact between the Contractor and the State. The Project Manager will be the State’s representative authorized to communicate the State’s position and directions related to all contract work and to coordinate all change orders with the Commissioner of Buildings and General Services as deemed necessary. 3.2.2 If applicable, the State shall furnish all surveys describing the physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site. 3.2.3 Except as provided in Subparagraph 4.7.1, the State shall secure and pay for necessary approvals, easements, assessments and charges required for the construction, use or occupancy of permanent structures or for permanent changes in existing facilities. 3.2.4 Information or services under the State's control shall be furnished by the State with reasonable promptness to avoid delay in the orderly progress of the Work. 3.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, all copies of Drawings and Specifications reasonably necessary for the execution of the Work. 3.2.6 The State shall forward instructions to the Contractor through the Architect. 3.2.7 The foregoing are in addition to any other duties and responsibilities of the State enumerated in the Contract Documents including those responsibilities described in Articles 6, 9 and 11 of this agreement. 3.2.8 The State may utilize a Clerk-of-the-Works to provide inspection and monitoring work on behalf of the State. If a Clerk-of-the-Works is utilized, it is the responsibility of the Architect and the Contractor to review and understand the Clerk’s duties, responsibilities and limitations of authority. Upon request, the State shall provide a copy of the Clerk-of-the-Works contract to Architect and Contractor.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services. 12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any. 12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
Responsibilities of the Transfer Agent The Transfer Agent undertakes the duties and obligations imposed by this Agreement upon the following terms and conditions, by all of which the Fund, by its acceptance hereof, shall be bound: 11.1 Whenever in the performance of its duties hereunder the Transfer Agent shall deem it necessary or desirable that any fact or matter be proved or established prior to taking or suffering any action hereunder, such fact or matter may be deemed to be conclusively proved and established by a certificate signed by an officer of the Fund and delivered to the Transfer Agent. Such certificate shall be full authorization to the recipient for any action taken or suffered in good faith by it under the provisions of this Agreement in reliance upon such certificate. 11.2 The Fund agrees that it will perform, execute, acknowledge and deliver or cause to be performed, executed, acknowledged and delivered all such further and other acts, instruments and assurances as may reasonably be required by the Transfer Agent for the carrying out, or performing by the Transfer Agent of the provisions of this Agreement.
RESPONSIBILITIES OF CITY City or its representative shall issue all communications to Contractor. City has the authority to request changes in the work in accordance with the terms of this Agreement and with the terms in Exhibit A – Scope of Work. City has the authority to stop work or to suspend any work.
Responsibilities of Contractor A. The Contractor shall perform all work on the described project as required by the Contract documents. The work to be performed includes the labor and services necessary to produce such replacement, and all materials, supplies, tools, transportation, equipment, and machinery required for replacement. B. This project bid includes all materials, labor and equipment to complete the reconstruction and resurfacing of streets as outlined in the Project Manual for WWREYN - XXXXXXXX SANITARY SEWER - PHASE 1 dated March 25th, 2021 as outlined in Attachment A.
Duties and Responsibilities of the Escrow Agent The Escrow Agent's duties and responsibilities shall be subject to the following terms and conditions: (a) The Subscriber and Company acknowledge and agree that the Escrow Agent (i) shall not be responsible for or bound by, and shall not be required to inquire into whether either the Subscriber or Company is entitled to receipt of the Company Documents and Subscriber Documents pursuant to, any other agreement or otherwise; (ii) shall be obligated only for the performance of such duties as are specifically assumed by the Escrow Agent pursuant to this Agreement; (iii) may rely on and shall be protected in acting or refraining from acting upon any written notice, instruction, instrument, statement, request or document furnished to it hereunder and believed by the Escrow Agent in good faith to be genuine and to have been signed or presented by the proper person or party, without being required to determine the authenticity or correctness of any fact stated therein or the propriety or validity or the service thereof; (iv) may assume that any person believed by the Escrow Agent in good faith to be authorized to give notice or make any statement or execute any document in connection with the provisions hereof is so authorized; (v) shall not be under any duty to give the property held by Escrow Agent hereunder any greater degree of care than Escrow Agent gives its own similar property; and (vi) may consult counsel satisfactory to Escrow Agent, the opinion of such counsel to be full and complete authorization and protection in respect of any action taken, suffered or omitted by Escrow Agent hereunder in good faith and in accordance with the opinion of such counsel. (b) The Subscriber and Company acknowledge that the Escrow Agent is acting solely as a stakeholder at their request and that the Escrow Agent shall not be liable for any action taken by Escrow Agent in good faith and believed by Escrow Agent to be authorized or within the rights or powers conferred upon Escrow Agent by this Agreement. The Subscriber and Company, jointly and severally, agree to indemnify and hold harmless the Escrow Agent and any of Escrow Agent's partners, employees, agents and representatives for any action taken or omitted to be taken by Escrow Agent or any of them hereunder, including the fees of outside counsel and other costs and expenses of defending itself against any claim or liability under this Agreement, except in the case of gross negligence or willful misconduct on Escrow Agent's part committed in its capacity as Escrow Agent under this Agreement. The Escrow Agent shall owe a duty only to the Subscriber and Company under this Agreement and to no other person. (c) The Subscriber and Company jointly and severally agree to reimburse the Escrow Agent for outside counsel fees, to the extent authorized hereunder and incurred in connection with the performance of its duties and responsibilities hereunder. (d) The Escrow Agent may at any time resign as Escrow Agent hereunder by giving five (5) days prior written notice of resignation to the Subscriber and the Company. Prior to the effective date of the resignation as specified in such notice, the Subscriber and Company will issue to the Escrow Agent a Joint Instruction authorizing delivery of the Company Documents and Subscriber Documents to a substitute Escrow Agent selected by the Subscriber and Company. If no successor Escrow Agent is named by the Subscriber and Company, the Escrow Agent may apply to a court of competent jurisdiction in the State of New York for appointment of a successor Escrow Agent, and to deposit the Company Documents and Subscriber Documents with the clerk of any such court. (e) The Escrow Agent does not have and will not have any interest in the Company Documents and Subscriber Documents, but is serving only as escrow agent, having only possession thereof. The Escrow Agent shall not be liable for any loss resulting from the making or retention of any investment in accordance with this Escrow Agreement. (f) This Agreement sets forth exclusively the duties of the Escrow Agent with respect to any and all matters pertinent thereto and no implied duties or obligations shall be read into this Agreement. (g) The Escrow Agent shall be permitted to act as counsel for the Subscriber in any dispute as to the disposition of the Company Documents and Subscriber Documents, in any other dispute between the Subscriber and Company, whether or not the Escrow Agent is then holding the Company Documents and Subscriber Documents and continues to act as the Escrow Agent hereunder. (h) The provisions of this Section 4.1 shall survive the resignation of the Escrow Agent or the termination of this Agreement.
Responsibilities of the Company 3.3.1 The Company shall provide participants of CopyTrade with a complete package of services according to the Customer Agreement. The Company is liable for proper performance of technological solutions according to the Customer Agreement. 3.3.2 The Company bears no liability to participants of CopyTrade for lost profit or losses, which may directly or indirectly occur as a result of trading operations performed or not performed by an Investor or a Trader. 3.3.3 The Company bears no liability to participants of CopyTrade for lost profit or losses, which may be directly or indirectly occur as a result of their ignorance of regulatory documents or cooperation scheme. 3.3.4 The Company doesn’t evaluate Traders’ professional skills and suitability not on a single stage of their activity and bears no responsibility to Investors for any losses or lost profit they may incur. 3.3.5 The Company is not liable for:
Responsibilities of the Contractor The Contractor shall provide all technical and professional expertise, knowledge, management, and other resources required for accomplishing all aspects of the tasks and associated activities identified in the Scope of Work. In the event that the need arises for the Contractor to perform services beyond those stated in the Scope of Work, the Contractor and the City shall negotiate mutually agreeable terms and compensation for completing the additional services.
