Role of Project Manager and Extension Lessee Sample Clauses

Role of Project Manager and Extension Lessee. The Trustee must procure the Project Manager (during the term of the Project Management Agreement) and the Extension Lessee (after the term of the Project Management Agreement) to: (a) jointly undertake any Interface Risk Assessments, with the Landholder, as required under clause 6.1; and (b) negotiate in good faith to endeavour to agree to the Interface Risk Management Plan and any amendments to it, as disclosed agent for the Trustee.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Role of Project Manager and Extension Lessee. (a) The Landholder acknowledges that the Trustee has appointed the Project Manager under the Project Management Agreement as the disclosed agent of the Trustee for the purpose of: (i) performing the Trustee’s obligations; and (ii) exercising the Trustee’s rights (other than the Trustee’s rights under clauses 3.1 and 3.2 and its rights in respect of Disputes under clause 19), under this Agreement, other than to the extent such obligations and rights must, by operation of law, be personally performed or exercised by the Trustee, during the term of the Project Management Agreement. (b) The Landholder acknowledges that the Trustee has appointed the Extension Lessee under the Extension Infrastructure Lease as the disclosed agent of the Trustee for the purpose of: (i) performing the Trustee’s obligations; and (ii) exercising the Trustee’s rights (other than the Trustee’s rights under clauses 3.1 and 3.2 and its rights in respect of Disputes under clause 19), under this Agreement, other than to the extent such obligations and rights must, by operation of law, be personally performed or exercised by the Trustee, following the termination of the Project Management Agreement.
Sample 1Sample 2

Related to Role of Project Manager and Extension Lessee

  • Outside Activities of Limited Partners Subject to any agreements entered into by a Limited Partner or its Affiliates with the General Partner, Partnership or a Subsidiary, any Limited Partner and any officer, director, employee, agent, trustee, Affiliate or stockholder of any Limited Partner shall be entitled to and may have business interests and engage in business activities in addition to those relating to the Partnership, including business interests and activities in direct competition with the Partnership or that are enhanced by the activities of the Partnership. Neither the Partnership nor any Partners shall have any rights by virtue of this Agreement in any business ventures of any Limited Partner or Assignee. Subject to such agreements, none of the Limited Partners nor any other Person shall have any rights by virtue of this Agreement or the partnership relationship established hereby in any business ventures of any other Person, other than the Limited Partners benefiting from the business conducted by the General Partner, and such Person shall have no obligation pursuant to this Agreement to offer any interest in any such business ventures to the Partnership, any Limited Partner or any such other Person, even if such opportunity is of a character which, if presented to the Partnership, any Limited Partner or such other Person, could be taken by such Person.

  • Data Protection Impact Assessment and Prior Consultation Processor shall provide reasonable assistance to the Company with any data protection impact assessments, and prior consultations with Supervising Authorities or other competent data privacy authorities, which Company reasonably considers to be required by article 35 or 36 of the GDPR or equivalent provisions of any other Data Protection Law, in each case solely in relation to Processing of Company Personal Data by, and taking into account the nature of the Processing and information available to, the Contracted Processors.

  • Coordination, Oversight and Monitoring of Service Providers As set forth in the Administrative Services Agreement between the Fund and CRMC, CRMC shall coordinate, monitor and oversee the activities performed by the Service Providers with which AFS contracts. AFS shall monitor Service Providers’ provision of services including the delivery of Customer account statements and all Fund-related material, including summary prospectuses and/or prospectuses, shareholder reports, and proxies.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:

  • Project Management and Coordination The Engineer shall coordinate all subconsultant activity to include quality of and consistency of work and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.

  • Responsibilities of Both Parties 6.1 The CLEC providing the circuit between CLEC’s office and SBC-12STATE’s office shall make such circuits available for use in connection with the DA services covered herein. When the total traffic exceeds the capability of the existing circuits, additional circuits will be provided by the CLEC. 6.2 Where applicable, if additional ADAX cards and ASN Routers (with sync and token ring cards) are necessary, they will be provided by SBC-12STATE, and CLEC will reimburse SBC-12STATE for the cost, plus Engineering, Furnish and Installation.

  • Project Manager, County The County shall appoint a Project Manager to act as liaison between the County and the Subrecipient during the term of this Contract. The County’s Project Manager shall coordinate the activities of the County staff assigned to work with the Subrecipient.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!