Schedule and Completion The Pre-commencement Phase Services to be performed under this Contract shall commence upon the Effective Date of the Contract and be completed within 60 days thereafter. Activities on the Site shall commence on the date specified in the Proceed Order and shall be materially complete in accordance with established Milestones, and not later than the Material Completion and Occupancy Date.
Time Schedule 4.1. A project schedule is included in Appendix A.
4.2. Any delay of services or change in sequence of tasks must be approved in writing by Delaware.
4.3. In the event that Vendor fails to complete the project or any phase thereof within the time specified in the Contract, or with such additional time as may be granted in writing by Delaware, or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this Agreement or any extensions thereof, Delaware shall suspend the payments scheduled as set forth in Appendix A.
Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.
SCHEDULE AND MILESTONES The Parties shall execute one (1) Annex concurrently with this Umbrella Agreement. The initial Annex and any subsequent Annexes will be performed on the schedule and in accordance with the milestones set forth in each respective Annex.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
Milestone Schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.
Work Schedule (A) Where an employee has an established schedule, a change in workdays or shifts will be posted no less than 14 calendar days in advance and will reflect at least a two workweek schedule; however, the state will make a good faith effort to reflect a one month schedule.
(B) In the event of a declared emergency the notice requirement of this Section may be void.
(C) The state will continue to observe the scheduling structures currently in place at each agency and agrees to bargain any change in the overall practice of how schedules are established.
Contract Schedule The information set forth in the Contract Schedule is true and correct.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
TIME OF COMPLETION This project’s start date is scheduled for June 15, 2015 and completion date is July 31, 2015. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 31st day of July, 2015, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.
