Scope Change Due to Certain Conditions Sample Clauses

Scope Change Due to Certain Conditions. To the extent an ARCA Delay Event described in clause (b)(A), (b)(B), (b)(C) or (b)(E) of the definition thereof causes a material delay in Contractor’s performance of the Work that Contractor cannot, in the absence of incurring material cost or impacting the critical path, overcome the effect thereof, Contractor shall be entitled to claim a Scope Change Order in accordance with the procedures of this Article 12 to appropriately adjust one or more of the Project Schedule, the Payment and Values Schedule and the Guaranteed Substantial Completion Date (but not the Contract Sum). Concessionaire’s obligation to extend the Guaranteed Completion Date as a result of such a Scope Change Order shall be subject to Concessionaire’s receipt of approval thereof from VDOT under the Comprehensive Agreement. Concessionaire shall proceed in accordance with Section 12.15(c) hereof to obtain such approval under the Comprehensive Agreement. The provisions of Section 12.15 hereof shall apply in the event Contractor and Concessionaire cannot agree on the length of the extension to be sought amount from VDOT pursuant to the Comprehensive Agreement in respect of such a Scope Change Order.
Sample 1
AutoNDA by SimpleDocs

Related to Scope Change Due to Certain Conditions

  • Certain Conditions Except as otherwise provided in Sections 2.2.4 and 2.3.4 of this Agreement, no Lender shall have an obligation to make any Loan, or to permit the continuation of or any conversion into any LIBOR Loan, and the Issuing Lender shall not have any obligation to issue any Letter of Credit, if an Event of Default or Unmatured Event of Default exists.

  • Termination Conditions Such license shall not be terminated or its exploitation enjoined, until and unless: (i) Hitachi has committed a material breach of its obligations under this IP License Agreement, Opto-Device has given written notice of such breach to Hitachi and such breach remains uncured after the Cure Period, or, in the case of a breach, which cannot be cured within such Cure Period, Hitachi has not instituted within such Cure Period steps necessary to remedy the default and/or thereafter has not diligently pursued the same to completion; or (ii) such a material breach is incurable. In the event the breach is a curable breach that cannot be cured within the Cure Period but with respect to which Hitachi has instituted steps necessary to remedy the default and is thereafter diligently pursuing such cure, both parties shall negotiate to determine whether further pursuit of such cure is reasonable. If the parties cannot agree on a resolution in such negotiations, then this issue shall be referred to arbitration pursuant to the arbitration procedures set forth in Exhibit B hereto to decide whether such breach can be cured or any other alternative remedy should be adopted. In the event the breach is an incurable breach, the parties agree that the matter shall be referred to arbitration pursuant to the arbitration procedures set forth in Exhibit B hereto to determine the appropriate remedy. In the event that either party submits the dispute to arbitration, both parties shall cooperate in such binding arbitration in accordance with Exhibit B.

  • Test conditions 6.1.1. The test shall be performed on a flat, dry concrete or asphalt surface affording good adhesion. 6.1.2. The ambient temperature shall be between 0°C and 45°C. 6.1.3. The horizontal visibility range shall allow the target to be observed throughout the test.

  • Changes in Condition In the event of any advantageous technical changes and/or downward pricing of the Services during the duration of this Agreement, the Contractor shall notify UNDP immediately. UNDP shall consider the impact of any such event and may request an amendment to the Agreement.

  • Adverse Changes in Condition Each Party agrees to give written notice promptly to the other Party upon becoming aware of the occurrence or impending occurrence of any event or circumstance relating to it or any of its Subsidiaries which (i) is reasonably likely to have, individually or in the aggregate, a Material Adverse Effect on it or (ii) would cause or constitute a material breach of any of its representations, warranties, or covenants contained herein, and to use its reasonable efforts to prevent or promptly to remedy the same.

  • Legal Conditions to the Merger (a) Subject to the terms hereof, the Company and the Fund shall each use its reasonable best efforts to (i) take, or cause to be taken, all actions, and do, or cause to be done, and to assist and cooperate with the other parties in doing, all things necessary, proper or advisable to consummate and make effective the Merger and the other transactions contemplated hereby and by the Company Stockholders’ Agreement as promptly as practicable, (ii) as promptly as practicable, obtain from any Governmental Entity or any other third party any consents, licenses, permits, waivers, approvals, authorizations, or orders required to be obtained or made by the Company, Acquisition LLC or the Fund or any of their Subsidiaries in connection with the authorization, execution and delivery of this Agreement and the Company Stockholders’ Agreement and the consummation of the transactions contemplated hereby and thereby, (iii) as promptly as practicable, make all necessary filings, and thereafter make any other required submissions, with respect to this Agreement and the Company Stockholders’ Agreement, and the Merger required under (A) the Securities Act and the Exchange Act, and any other applicable federal or state securities laws, and (B) any other applicable law and (iv) execute or deliver any additional instruments necessary to consummate the transactions contemplated by, and to fully carry out the purposes of, this Agreement and the Company Stockholders’ Agreement. The Company and the Fund shall cooperate with each other in connection with the making of all such filings. The Company and the Fund shall use their respective reasonable efforts to furnish to each other all information required for any application or other filing to be made pursuant to the rules and regulations of any applicable law (including all information required to be included in the Proxy Statement and the Registration Statement) in connection with the transactions contemplated by this Agreement and the Company Stockholders’ Agreement. (b) Each of the Company and the Fund shall give (or shall cause their respective Subsidiaries to give) any notices to third parties, and use, and cause their respective Subsidiaries to use, their reasonable efforts to obtain any third party consents related to or required in connection with the Merger that are (i) necessary to consummate the transactions contemplated hereby or in the Company Stockholders’ Agreement, (ii) disclosed or required to be disclosed in the Company Disclosure Schedule or the Fund Disclosure Schedule, as the case may be, or (iii) required to prevent a Company Material Adverse Effect or a Fund Material Adverse Effect from occurring prior to or after the Effective Time.

  • Adjustments Upon Specified Events Upon the occurrence of certain events relating to the Corporation’s stock contemplated by Section 7.1 of the Plan (including, without limitation, an extraordinary cash dividend on such stock), the Administrator shall make adjustments in accordance with such section in the number of Stock Units then outstanding and the number and kind of securities that may be issued in respect of the Award. No such adjustment shall be made with respect to any ordinary cash dividend for which dividend equivalents are credited pursuant to Section 5(b).

  • Certain Conditions to Assignments Assignments shall be subject to the following additional conditions: (A) except in the case of an assignment to a Lender or an Affiliate of a Lender or an assignment of the entire remaining amount of the assigning Xxxxxx’s Commitment or Loans and LC Exposure of a Class, the amount of the Commitment or Loans and LC Exposure of such Class of the assigning Lender subject to each such assignment (determined as of the date the Assignment and Assumption with respect to such assignment is delivered to the Administrative Agent) shall not be less than U.S. $5,000,000 unless each of the Borrower and the Administrative Agent otherwise consent; (B) each partial assignment of any Class of Commitments or Loans and LC Exposure shall be made as an assignment of a proportionate part of all the assigning Lender’s rights and obligations under this Agreement in respect of such Class of Commitments, Loans and LC Exposure; (C) the parties to each assignment shall execute and deliver to the Administrative Agent an Assignment and Assumption, together with a processing and recordation fee of U.S. $3,500 (which fee shall not be payable in connection with an assignment to a Lender or to an Affiliate of a Lender) (for which no Obligor shall be obligated); and (D) the assignee, if it shall not already be a Lender of the applicable Class, shall deliver to the Administrative Agent an Administrative Questionnaire.

  • SPECIAL CONDITIONS A submitted appeal must;

  • Failure to Satisfy Conditions If the Secured Party or its Custodian fails to satisfy any conditions for holding Posted Collateral, then upon a demand made by the Pledgor, the Secured Party will, not later than five Local Business Days after the demand, Transfer or cause its Custodian to Transfer all Posted Collateral held by it to a Custodian that satisfies those conditions or to the Secured Party if it satisfies those conditions.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!