Felling of trees The Authority shall assist the Contractor in obtaining the Applicable Permits for felling of trees in non-forest area to be identified by the Authority for this purpose if, and only if, such trees cause a Material Adverse Effect on the construction or maintenance of the Project Highway. The Contractor shall fell these trees as per the Permits obtained. The cost of such felling shall be borne by the Authority and in the event of any delay in felling thereof for reasons beyond the control of the Contractor; it shall be excused for failure to perform any of its obligations hereunder if such failure is a direct consequence of delay in the felling of trees. The Parties hereto agree that the felled trees shall be deemed to be owned by the Authority and shall be disposed in such manner and subject to such conditions as the Authority may in its sole discretion deem appropriate. For the avoidance of doubt, the Parties agree that if any felling of trees hereunder is in a forest area, the Applicable Permit thereof shall be procured by the Authority within the time specified in the Agreement.
Summer Session A. All ASEs employed in the Summer Session shall receive the same general range adjustment as ASEs received in the preceding Fall term. B. The following articles apply to ASEs who are employed in the summer session: Recognition, Wages (range adjustment only), DCP, Travel, Health and Safety, Leaves, Holidays, Duration, Workspace and Instructional Support, Parking, Grievance and Arbitration, Waiver, Management and Academic Rights, No Strikes, Non-Discrimination, Union Access and Rights, Union Security, Discipline and Dismissal, Emergency Layoff, Employment Files and Evaluations, Definitions, Severability, Labor-Management Meetings, and Classifications. C. The remainder of the articles in the agreement does not apply to ASEs who are employed in the summer session. D. The topic of Summer Session, and effects of changes on terms and conditions of employment for ASEs employed in Summer Session, shall be reopened for bargaining commencing no later than January 2, 2001.
Sealing and Marking of Bids The bidder shall seal the original and each copy of the bid in separate envelopes duly marking the envelopes “ORIGINAL” and “COPY”. The envelopes shall then be sealed in an outer separate envelope.
RUNNING OF THE ACADEMY Teachers and staff
Shifting of obstructing utilities The Contractor shall, in accordance with Applicable Laws and with assistance of the Authority, undertake the work of shifting of any utility (including electric lines, water pipes, gas pipelines and telephone cables) to an appropriate location or alignment, if such utility or obstruction adversely affects the execution of Works or Maintenance of the Project Highway in accordance with this Agreement. The cost of such shifting, as per estimates prepared by the entity owning the utility and approved by the Authority, shall be reimbursed by the Authority to the Contractor. The scope of work of such shifting of Utilities shall be as indicated in Schedule-B-1. In the event of any delay of such shifting on the part of the contractor, no extension of time for completion of the project and no claims, in any manner, shall be admissible on this account against the Authority. The work of shifting of Utilities can be taken up by the Contractor any time after signing of the Agreement.
Filling of Positions The parties agree that all appointments to vacancies covered by this Agreement shall be filled by the Employer with the procedure outlined in this Article. The parties recognize that the Employer has the exclusive authority to determine if and when vacancies are to be filled and the qualifications required of those positions.
Format and Signing of Tender 19.1 The Tenderer shall prepare one original of the documents comprising the Tender as described in ITT 11 and clearly mark it “ORIGINAL.” Alternative Tenders, if permitted in accordance with ITT 12, shall be clearly marked “ALTERNATIVE.” In addition, the Tenderer shall submit copies of the Tender, in the number specified in the TDS and clearly mark them “COPY.” In the event of any discrepancy between the original and the copies, the original shall prevail. 19.2 Tenderers shall mark as “CONFIDENTIAL” information in their Tenders which is confidential to their business. This may include proprietary information, trade secrets, or commercial or financially sensitive information. 19.3 The original and all copies of the Tender shall be typed or written in indelible ink and shall be signed by a person duly authorized to sign on behalf of the Tenderer. This authorization shall consist of a written confirmation as specified in the TDS and shall be attached to the Tender. The name and position held by each person signing the authorization must be typed or printed below the signature. All pages of the Tender where entries or amendments have been made shall be signed or initialed by the person signing the Tender. 19.4 In case the Tenderer is a JV, the Tender shall be signed by an authorized representative of the JV on behalf of the JV, and so as to be legally binding on all the members as evidenced by a power of attorney signed by each members' legally authorized representatives. 19.5 Any inter-lineation, erasures, or overwriting shall be valid only if they are signed or initialed by the person signing the Tender.
Resealing of Documents Once the work has been sealed and accepted by the State, the State, as the owner, will notify the party to this contract, in writing, of the possibility that a State engineer, as a second engineer, may find it necessary to alter, complete, correct, revise or add to the work. If necessary, the second engineer will affix his seal to any work altered, completed, corrected, revised or added. The second engineer will then become responsible for any alterations, additions or deletions to the original design including any effect or impacts of those changes on the original engineer’s design.
Vacancy Posting If a regular employee is absent from his/her position for more than 24 months as a result of medical leave, such position will be posted in accordance with the provision of Article 12. Upon return to work the regular employee shall be returned to work to a position of equal rank and basic pay.
Appointment Above Entrance Rate 242. Appointments may be made by an appointing officer at any step in the salary grade upon the approval of the Human Resources Director under one or more of the following conditions: a. A former permanent City employee, following resignation with service satisfactory, is being reappointed to a permanent position in his/her former classification. 244. b. Loss of compensation would result if appointee accepts position at the normal step.