Xxxxxxxx’s Right to Reinstate After Acceleration If Borrower meets certain conditions, Borrower shall have the right to have enforcement of this Security Instrument discontinued at any time prior to the earliest of: (a) five days before sale of the Property pursuant to any power of sale contained in this Security Instrument; (b) such other period as Applicable Law might specify for the termination of Borrower’s right to reinstate; or (c) entry of a judgment enforcing this Security Instrument. Those conditions are that Borrower: (a) pays Lender all sums which then would be due under this Security Instrument and the Note as if no acceleration had occurred; (b) cures any default of any other covenants or agreements; (c) pays all expenses incurred in enforcing this Security Instrument, including, but not limited to, reasonable attorneys’ fees, property inspection and valuation fees, and other fees incurred for the purpose of protecting Lender’s interest in the Property and rights under this Security Instrument; and (d) takes such action as Lender may reasonably require to assure that Xxxxxx’s interest in the Property and rights under this Security Instrument, and Borrower’s obligation to pay the sums secured by this Security Instrument, shall continue unchanged. Lender may require that Borrower pay such reinstatement sums and expenses in one or more of the following forms, as selected by Lender: (a) cash; (b) money order; (c) certified check, bank check, treasurer’s check or cashier’s check, provided any such check is drawn upon an institution whose deposits are insured by a federal agency, instrumentality or entity; or (d)
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.
Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to Refuse Unsafe Work Employees have the right to refuse to perform unsafe work pursuant to the Occupational Health and Safety Regulations of the Workers Compensation Act.
Right to Open Up 13.3 Subject to Clause 13.4 (Right to Open Up), the Authority's Representative shall have the right at any time prior to[:
Xxxxxxxx’s Right to Reinstate the Loan after Acceleration If Xxxxxxxx meets certain conditions, Borrower will have the right to reinstate the Loan and have enforcement of this Security Instrument discontinued at any time up to the later of (a) five days before any foreclosure sale of the Property, or (b) such other period as Applicable Law might specify for the termination of Xxxxxxxx’s right to reinstate. This right to reinstate will not apply in the case of acceleration under Section 19. To reinstate the Loan, Borrower must satisfy all of the following conditions: (aa) pay Lender all sums that then would be due under this Security Instrument and the Note as if no acceleration had occurred; (bb) cure any Default of any other covenants or agreements under this Security Instrument or the Note; (cc) pay all expenses incurred in enforcing this Security Instrument or the Note, including, but not limited to: (i) reasonable attorneys’ fees and costs; (ii) property inspection and valuation fees; and (iii) other fees incurred to protect Xxxxxx’s interest in the Property and/or rights under this Security Instrument or the Note; and (dd) take such action as Lender may reasonably require to assure that Xxxxxx’s interest in the Property and/or rights under this Security Instrument or the Note, and Xxxxxxxx’s obligation to pay the sums secured by this Security Instrument or the Note, will continue unchanged. Lender may require that Borrower pay such reinstatement sums and expenses in one or more of the following forms, as selected by Lender: (aaa) cash; (bbb) money order; (ccc) certified check, bank check, treasurer’s check, or cashier’s check, provided any such check is drawn upon an institution whose deposits are insured by a U.S. federal agency, instrumentality, or entity; or (ddd) Electronic Fund Transfer. Upon Xxxxxxxx’s reinstatement of the Loan, this Security Instrument and obligations secured by this Security Instrument will remain fully effective as if no acceleration had occurred.
STATE'S RIGHT TO STOP THE WORK 3.3.1 If the Contractor fails to correct defective Work as required by Paragraph 13.2 or persistently fails to carry out the Work in accordance with the Contract Documents, the State, by a written order signed personally or by an agent specifically so empowered by the State in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of the State to the stop the Work shall not give rise to any duty on the part the State to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Subparagraph 6.1.3.
Owner’s Right to Perform Work The Owner reserves the right to perform construction or operations related to the Project with Separate Contractors on the Site. If the Contractor claims that delay or additional cost is because of such action by the Owner, the Contractor shall assert such claims as provided in Section 5, Part 2 of the General Conditions.
