Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Post-Closing Deliverables (a) Within ten (10) days of the Closing Date, Seller and/or Seller’s Affiliates shall give any notices required to be given under the Material Contracts in connection with the consummation of the Transaction and shall further provide to Purchaser at Closing with true and complete copies of such notices. From and following the date of this Agreement, Seller and the Company shall use commercially reasonable efforts to (i) obtain any consents or authorizations required under the terms of the Material Contracts in connection with the consummation of the Transaction and (ii) prepare the documents to be executed pursuant to Section 2.2(e) as required under the terms of the Material Contracts in connection with the consummation of the Transaction. If, as of Closing (i) any notice has not been given or any authorization or consent has not been obtained under the terms of the Contracts included in the Assets (including as may be required under the terms of the Assumed Contracts in connection with the consummation of the Transaction) or (ii) any conveyance or assignment documents required to vest title to all Owned Real Property and easements in the Company have not been executed prior to Closing, in each case other quitclaim deeds with respect to Owned Office Properties as specifically required to be delivered at Closing in accordance with Section 2.2(e), notwithstanding anything in this Agreement to the contrary, such failure shall not give rise to any right to indemnification under Article IX.
(b) Seller shall (i) for twelve (12) months following the Closing Date, use commercially reasonable efforts to, as and when requested by Purchaser, give any notice that has not been given or obtain any authorization or consent that has not been obtained prior to the Closing that is required under the terms of the Contracts included in the Assets (including as may be required under the terms of the Assumed Contracts in connection with the consummation of the Transaction) and (ii) as soon as practicable following Closing (but no more than 90 days following Closing), deliver to Purchaser an accurate list and description of all Owned Real Property and execute and deliver to Purchaser all real estate conveyance documents required to vest title to all Owned Real Property and easements in the Company (to the extent not previously delivered at Closing). Following Closing, until such required notices are given or such required consents are obtained or such documents are executed, Seller agrees to enter into a commercially reasonable alternative arrangement to provide (and cause its Affiliates to provide, as applicable), the Company and Purchaser’s Affiliates with the benefits (e.g., in respect of any applicable Sign Location Lease, the right to operate the Structures on the property covered thereby) to which such notice or consent relates, including by enforcing at the written request of Purchaser (and at Purchaser’s sole cost and expense) any of the rights under such Contract (including the right of termination); and to the extent the Company (or Purchaser’s Affiliate) receives such benefits (or Seller enforces any rights under such Contract at Purchaser’s written request), Purchaser shall be responsible for the performance of the Seller’s obligations thereunder, at Purchaser’s sole cost and expense, acting in good faith and in the ordinary course of business. If within the twelve (12) month period following the Closing Date (aa) either Party (or their Affiliates) receives written notice from a landowner or counterparty (or counsel for the landowner or counterparty) purporting to terminate a particular Sign Location Lease which is a Material Contract or a Bus Transit Contract, as a result of the failure to obtain a consent required by the terms of such lease or Bus Transit Contract, or (bb) any such landlord or counterparty files suit (or initiates arbitration, if applicable) against either Party (or their respective Affiliates) seeking termination of the applicable Sign Location Lease or Bus Transit Contract, as a result of the failure to obtain a consent required by the terms of such lease or Bus Transit Contract, or (cc) any such landowner or counterparty requires payment of a material sum or some other material concession from the Company in exchange for any such required consent (and in the case of a demand for a material sum of money, where Seller elects to not pay such amount upon request of the Company), then in each such instance, the Company or Purchaser may within ten days following the expiration of such twelve month period (or such later period as provided below) by written notice to Seller either (i) elect to relinquish all of its right, title and interest in and to such Sign Location Lease or Bus Transit Contract, as applicable (and any Assets solely related thereto), to Seller, in which case the Purchaser shall be entitled to a payment from Seller in an amount equal to that portion of the Purchase Price allocable to such item or asset, which shall be based on a multiple equal to the product of 7.1 times net revenues less site lease expense for calendar year 2014; or (ii) elect to retain such rights over the item or asset, in which case there would be no such payment to the Company or Purchaser, as applicable; provided, however, that (x) Purchaser shall upon request by Seller, assist and cooperate with Seller in effecting the commercially reasonable alternative arrangement referred to above and in obtaining the applicable required consent, and (y) before Purchaser shall have the right to exercise its rights under subpart (i) above, Seller shall have the right (at Seller’s sole cost) to defend any such action by a landlord or counterparty and/or to negotiate a settlement and/or cure any alleged breach of the applicable lease or Bus Transit Contract and so long as Seller is diligently doing so, Seller shall have until the expiration of the following periods to cure or settle such matter (i) if Purchaser is still permitted to operate at such location during the pendency of such matter, until such matter is finally adjudicated or (ii) if Purchaser is not permitted to operate at such location during the pendency of such matter and Seller elects not to replace the lost net cash flow at such location during the pendency of such matter, a two (2) month period from the date Purchaser is first not able to operate at such location (provided, further, that, in the case of both (i) and (ii) above, if Purchaser in good faith determines that the Company or Purchaser’s applicable Affiliate could reasonably be expected to be subject to liability to such landlord or counterparty by continuing to operate such asset, Purchaser may require that Seller confirm in writing to Purchaser Seller’s duty to defend and indemnify Purchaser with respect thereto, including but not limited to damages for trespass, where applicable). Purchaser acknowledges that failure to timely notify Seller of such an election in accordance with the foregoing shall be deemed an acceptance by Purchaser of such Sign Location Lease or Bus Transit Contract, as applicable and related Assets and a relinquishment of any right to payment from Seller. For the avoidance of doubt, any amounts that may become due to Purchaser (or the Company) under this paragraph shall not be subject to the limitations set forth in Section 9.2(c).
(c) As soon as practicable following the Closing (but no later than 90 days following Closing), Seller shall deliver to Purchaser Outdoor Advertising Permit transfer documents as are required to validly and fully transfer and assign all such Permits to the Company (or Purchaser’s designated Affiliate).
Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.
Sale : Completion On Or Before The Completion Date
a. Within ninety (90) days from the date of successful sale (the expiry date of which period referred to as “the Completion Date”), the Purchaser shall deposit with the Assignee’s Solicitors simultaneously:-
(i) The balance of the purchase price i.e a sum equivalent to 90% of the successful bid price (referred to as “the Balance Sum”) either by way of IBG or XXXXXX or bank draft or cashier’s order crossed “A/C PAYEE ONLY” made payable to HONG XXXXX BANK BERHAD. The amount of the bank draft or cashier’s order shall include outstation clearing charges which shall be borne by the Purchaser, failing which the deficiency shall be recoverable from the Purchaser; and
(ii) A copy of the requisite consents or confirmations (as the case may be) of the Developer and/or Proprietor and/or State Authorities and/or relevant bodies approving the sale (including transfer or assignment) in favour of the Purchaser, if necessary and/or required, subject firstly to the Assignee being satisfied with the conditions if imposed, otherwise the Assignee may elect to terminate the sale under Xxxxxx 11. - Extension
b. The Completion Date will not be extended unless the Purchaser shall have at least fourteen (14) days before the Completion Date applied in writing for an extension of time to the Assignee and the Assignee may at its absolute discretion without assigning any reason whatsoever either:-
(i) Reject such request in which event all monies paid by the Purchaser hitherto including the Deposit shall be forfeited absolutely and immediately for which the Purchaser shall not be entitled to nor have any or further reimbursements, claims and demands whatsoever in nature and howsoever caused against the Assignee, the Assignee’s Solicitors, the Auctioneer or their respective servants or agents and any other party on account thereof; or
(ii) Agree to grant an extension of time subject to conditions imposed by the Assignee including but not limited to the imposition of non- refundable late payment charges / compensation charges on the balance unpaid or outstanding purchase price at such rate as the Assignee shall determine and to be calculated on a daily basis for the whole duration of the extended period granted and also to pay such sum within the time and in the manner as stipulated by the Assignee. Such decision by the Assignee shall be binding on the Purchaser. - Charges
c. Notwithstanding any contrary terms and conditions which may be imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto on the Assignee in granting the consent or confirmation (as the case may be) to the sale herein, it is hereby agreed that only arrears of quit rent, assessment rate and service charges (collectively referred to as “the Outstanding Charges”) within a period of six (6) years prior to the date of successful sale of the Property which are lawfully and rightfully due and payable to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto up to the date of successful sale of the Property shall be deducted from the purchase price upon receipt of the Balance Sum PROVIDED THAT the Assignee reserves the right to refuse to pay nor shall the Assignee be obliged to pay:-
(i) Any Outstanding Charges that are time-barred i.e. charges which have remained unpaid for more than six (6) years prior to the date of successful sale of the Property irrespective of any payment or acknowledgement or judgment made or obtained on the said charges;
(ii) Any Outstanding Charges that are excessively charged resulted from eg duplicate or double counting, wrong calculation or any other similar circumstances;
(iii) Any Outstanding Charges wrongfully imposed including but not limited to being charged without any basis whatsoever; and/or
(iv) Any bills issued by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto for the Outstanding Charges but only received by the Assignee or the Assignee’s Solicitors more than seventy-five (75) days from the date of the successful sale. Such decision by Assignee on what is due and payable shall be binding on the Purchaser of which the Purchaser hereby expressly agrees.
d. The Outstanding Charges due and payable immediately after the date of successful sale of the Property shall be solely borne and paid by the Purchaser.
e. Where applicable, it shall be the duty of the Purchaser to obtain at the Purchaser’s own costs the particulars as stated in Section 22D(4) of the Housing Development (Control and Licensing) Act 1966 and to obtain copies of the charges payable from the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto and to forward copies thereof together with the calculations as to the apportionment of the respective parties’ liability thereof to the Assignee’s Solicitors for the Assignee’s approval. For this purpose, the Purchaser shall also furnish the Assignee’s Solicitors with the Purchaser’s account details in order for the Assignee to process payment of the Assignee’s portion of the Outstanding Charges pursuant to and in accordance with Clause 8(c) above.
f. In the event the Purchaser shall pay such arrears (if any) of the Outstanding Charges in advance to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto:-
(i) The Purchaser is not entitled to deduct the payment towards the arrears (if any) from the Balance Sum;
(ii) Due apportionment and reimbursement for the payment (if any) made by the Purchaser towards the arrears shall only be made after the Assignee has received the Balance Sum and subject to the Assignee’s approval and other provisions of these Conditions of Sale. For this purpose, the Purchaser shall produce receipts evidencing payment together with the Purchaser’s account details in order for the Assignee to reimburse the Purchaser in accordance with this Clause 8(f)(ii) accordingly.
g. Nothing herein shall impose any obligation on the part of the Assignee to pay any outstanding water, electricity, telephone, utilities, gas, sewerage, taxes, rates, bills, any type of interest, fine, penalty, losses incurred by reason of any breach of written laws, late payment charges, damages, compensation, other form of maintenance or management charges (including but not limited to security charges, charges incurred in relation to car park / accessory parcel, deposits, sinking / building / common / maintenance / management fund), costs for renovation / alteration / additional works, contribution, subscription, licence, dues, levies, insurance, premium, rents, commission, fees, costs and expenses (including but not limited to legal fees, disbursements, stamp duty, registration fees, administrative or vetting fees and transfer costs), other outgoings and charges in any form whatsoever (including for any increase in area of the Property imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto irrespective of whether the same was imposed or incurred before the date of successful auction, any penalty thereof in connection with incidental to or pursuant to the Assignment the Memorandum of Transfer and all other documents necessary for affecting the transfer or subsequent transfer [as the case may be] or assigning the beneficial ownership of the Property to the Purchaser or that as may be due to or imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto notwithstanding that the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto may require such payments to be made by the Assignee). The Purchaser hereby expressly agrees that such costs and expenses shall be solely borne and paid by the Purchaser.
h. Any other costs, expenses and charges not specifically mentioned and/or specified in Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f and Clause 8.g hereof which are outstanding shall be solely borne and paid by the Purchaser.
i. Upon payment of all monies mentioned and/or specified in Clause 6.d, Clause 7.a, Clause 8.a(i), Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f, Clause 8.g and Clause 8.h above and subject to the fulfillment of Clause 9 below by the Purchaser, the Assignee shall:-
(i) Execute or cause to be executed as soon as possible at the Purchaser’s own costs and expenses (including legal fees, stamp duty and registration fees) an Assignment (in the form and substance acceptable to and upon the terms and conditions stipulated by the Assignee at its absolute discretion) in favour of the Purchaser of all the rights title interests and benefits under the Sale and Purchase Agreement entered into between the Developer and/or Proprietor of the Property and the Assignor or the original purchaser(s) when the Assignor is not the original purchaser of the Property. Where applicable, the Assignee shall be entitled to have a sufficient covenant of indemnity inserted in the Assignment in order for the Purchaser to assume all liabilities and obligations pertaining to the Property. The Assignee shall not be required to assign the Property to any person other than the Purchaser; and
(ii) Deliver to the Purchaser or the Purchaser’s Solicitors the duly executed Assignment and certified true copy(ies) of the Sale and Purchase Agreement and previous Assignment within the Assignee’s custody. If any of the aforesaid documents is not available, the Assignee shall use its best endeavors to provide certified true copy(ies) or such other acceptable documentary evidence of previous transactions thereof.
j. Where applicable, the Purchaser undertakes to forward to the Developer the duly stamped Assignment, the duly stamped Proclamation of Sale and the Memorandum together with the full payment of all sums and outgoings due to the Developer under the Sale and Purchase Agreement as required by Section 22D(2) of the Housing Development (Control and Licensing) Act 1966 within fourteen (14) days from the date of stamping of the Assignment and to forward a copy of the cover letter or acknowledgment of receipt by the Developer to the Assignee or the Assignee’s Solicitors within seven (7) days after the issuance of the cover letter or acknowledgment of receipt. - Charge / Transfer
k. If the separate document of title or strata title for the Property has been issued whether before on or after the date of auction sale, the Assignee shall not be required to procure a Memorandum of Transfer nor to register its charge as prescribed by the National Land Code 1965 or Sarawak Land Code or the Land Ordinance Cap. 68 of the Laws of Sabah (where applicable) in favour of the Purchaser from the Developer and/or Proprietor (as the case may be).
l. The transfer of the Property from the Developer and/or Proprietor (as the case may be) shall be prepared and procured by the Purchaser at the Purchaser’s own costs (including costs of transfer from the Developer and/or Proprietor to the Assignor where necessary) and expenses who undertakes to pay such sums and comply with the conditions (if any) imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies pertaining to the registration of such transfer of the Property.
m. The Purchaser undertakes to inform the local authority of the change of ownership and to file the necessary form within fourteen (14) days from the date of stamping of the Assignment.
Project Deliverables The Contractor shall provide each of the following deliverables in writing to the City for review and approval to achieve the project objectives.
C.1. <Title> Deliverable 1
Post-Closing Deliveries (a) The Borrower hereby agrees to deliver, or cause to be delivered, to the Administrative Agent, in form and substance reasonably satisfactory to the Administrative Agent, the items described on Schedule 5.15 hereof on or before the dates specified with respect to such items, or such later dates as may be agreed to by, or as may be waived by, the Administrative Agent in its sole discretion.
(b) All representations and warranties contained in this Agreement and the other Loan Documents shall be deemed modified to the extent necessary to effect the foregoing (and to permit the taking of the actions described above within the time periods required above and in Schedule 5.15, rather than as elsewhere provided in the Loan Documents); provided that (x) to the extent any representation and warranty would not be true because the foregoing actions were not taken on the Closing Date or, following the Closing Date, prior to the date by which such action is required to be taken by Section 5.15(a), the respective representation and warranty shall be required to be true and correct in all material respects at the time the respective action is taken (or was required to be taken) in accordance with the foregoing provisions of this Section 5.15 (and Schedule 5.15) and (y) all representations and warranties relating to the assets set forth on Schedule 5.15 pursuant to the Security Documents shall be required to be true in all material respects immediately after the actions required to be taken under this Section 5.15 (and Schedule 5.15) have been taken (or were required to be taken), except to the extent any such representations and warranties expressly relate to an earlier date, in which case such representations and warranties shall be true and correct in all material respects as of such earlier date.
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such
9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees.
9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims.
9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from:
(a) unsettled liens,
(b) faulty or defective Work appearing after Substantial Completion,
(c) failure of the Work to comply with the requirements of the Contract Documents, or
(d) terms of any special warranties required by the Contract Documents.
9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
