Security Management The Contractor shall comply with the requirements of the DOD 5200.1-M and the DD Form 254. Security of the Contractor’s electronic media shall be in accordance with the above documents. Effective Program Security shall require the Contractor to address Information Security and Operations Security enabled by the Security Classification Guides. The Contractor’s facility must be able to handle and store material up to the Classification Level as referenced in Attachment J-01, DD Form 254.
Contract Monitoring The criminal background checks required by this rule shall be national in scope, and must be conducted at least once every three (3) years. Contractor shall make the criminal background checks required by Paragraph IV.G.1 available for inspection and copying by DRS personnel upon request of DRS.
Project Monitoring The Developer shall provide regular status reports to the NYISO in accordance with the monitoring requirements set forth in the Development Schedule, the Public Policy Transmission Planning Process Manual and Attachment Y of the OATT.
Patch Management All workstations, laptops and other systems that process and/or 20 store PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or 21 transmits on behalf of COUNTY must have critical security patches applied, with system reboot if 22 necessary. There must be a documented patch management process which determines installation 23 timeframe based on risk assessment and vendor recommendations. At a maximum, all applicable 24 patches must be installed within thirty (30) calendar or business days of vendor release. Applications 25 and systems that cannot be patched due to operational reasons must have compensatory controls 26 implemented to minimize risk, where possible.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Program Monitoring The Contractor will make all records and documents required under this Agreement as outlined here, in OEC Policies and NHECC Policies available to the SRO or its designee, the SR Fiscal Officer or their designee and the OEC. Scheduled monitoring visits will take place twice a year. The SRO and OEC reserve the right to make unannounced visits.
Access Management The Engineer shall coordinate and evaluate access management within the project limits in accordance with the latest State Access Management Manual or as directed by the State.
Workload Management 11.1 The parties to this Agreement acknowledge that employees and management have a responsibility to maintain a balanced workload and recognise the adverse affects that excessive workloads may have on employee/s and the quality of resident/client care. 11.2 To ensure that employee concerns involving excessive workloads are effectively dealt with by Management the following procedures should be applied: (a) Step 1: In the first instance, employee/s should discuss the issue with their immediate supervisor and, where appropriate, explore solutions. (b) Step 2: If a solution cannot be identified and implemented, the matter should be referred to an appropriate senior manager for further discussion. (c) Step 3: If a solution still cannot be identified and implemented, the matter should be referred to the Facility Manager for further discussion. (d) Step 4: The outcome of the discussions at each level and any proposed solutions should be recorded in writing and fed back to the effected employees. 11.3 Workload management must be an agenda item at staff meetings on at least a quarterly basis. Items in relation to workloads must be recorded in the minutes of the staff meeting, as well as actions to be taken to resolve the workloads issue/s. Resolution of workload issues should be based on the following criteria including but not limited to: (a) Clinical assessment of residents’ needs; (b) The demand of the environment such as facility layout; (c) Statutory obligation, (including, but not limited to, work health and safety legislation); (d) The requirements of nurse regulatory legislation; (e) Reasonable workloads (such as roster arrangements); (f) Accreditation standards; and (g) Budgetary considerations. 11.4 If the issue is still unresolved, the employee/s may advance the matter through Clause 9 Dispute Resolution Procedure. Arbitration of workload management issues may only occur by agreement of the employer and the employee representative, which may include the union/s.
SITE MANAGEMENT We reserve the right, but not the obligation, to: (1) monitor the Site for violations of these Terms of Use; (2) take appropriate legal action against anyone who, in our sole discretion, violates the law or these Terms of Use, including without limitation, reporting such user to law enforcement authorities; (3) in our sole discretion and without limitation, refuse, restrict access to, limit the availability of, or disable (to the extent technologically feasible) any of your Contributions or any portion thereof; (4) in our sole discretion and without limitation, notice, or liability, to remove from the Site or otherwise disable all files and content that are excessive in size or are in any way burdensome to our systems; and (5) otherwise manage the Site in a manner designed to protect our rights and property and to facilitate the proper functioning of the Site.
Monitoring Services IDT staff shall, using methods that include face-to-face and other contacts with the member, monitor the services a member receives. This monitoring shall ensure that: a. The member receives the services and supports authorized, arranged for and coordinated by the IDT staff; b. The services and supports identified in the MCP as being provided by natural and community supports are being provided; and c. The quality of the services and supports received is adequate and still necessary to continue to meet the needs and preferences of the member and support the member’s outcomes identified in the MCP.