Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
General Maintenance Borrower shall maintain the Project Site and all improvements thereon, including lighting and signage, in good condition, free of debris, waste and graffiti, and in compliance with the applicable provisions of the Anaheim Municipal Code. Borrower shall maintain the improvements and landscaping on the Project Site in accordance with the Maintenance Standards (as hereinafter defined). Such Maintenance Standards shall apply to all buildings, signage, lighting, landscaping, irrigation of landscaping, architectural elements identifying the Project Site and any and all other improvements on the Project Site. To accomplish the maintenance, Borrower shall either staff or contract with and hire licensed and qualified personnel to perform the maintenance work, including the provision of labor, equipment, materials, support facilities, and any and all other items necessary to comply with the requirements of this Agreement. Borrower and its maintenance staff, contractors or subcontractors shall comply with the following standards (collectively, “Maintenance Standards”): (i) The Project Site shall be maintained in conformance and in compliance with reasonable maintenance standards for comparable first quality affordable housing projects, including but not limited to painting and cleaning of all exterior surfaces and other exterior facades comprising all private improvements and public improvements to the curbline. The Project Site shall be maintained in good condition and in accordance with the custom and practice generally applicable to comparable first quality affordable apartment complexes in the County of Orange (the “County”). (ii) Landscape maintenance shall include, but not be limited to: watering/irrigation; fertilization; mowing; edging; trimming of grass; tree and shrub pruning; trimming and shaping of trees and shrubs to maintain a healthy, natural appearance and safe road conditions and visibility, and irrigation coverage; replacement, as needed, of all plant materials; control of weeds in all planters, shrubs, lawns, ground covers, or other planted areas; and staking for support of trees. (iii) Clean-up maintenance shall include, but not be limited to: maintenance of all sidewalks, paths and other paved areas in clean and weed-free condition; maintenance of all such areas clear of dirt, mud, trash, debris or other matter which is unsafe or unsightly; removal of all trash, litter and other debris from improvements and landscaping prior to mowing; clearance and cleaning of all areas maintained prior to the end of the day on which the maintenance operations are performed to ensure that all cuttings, weeds, leaves and other debris are properly disposed of by maintenance workers. Governmental Lender agrees to notify Borrower in writing if the condition of the Project Site does not meet with the Maintenance Standards and to specify the deficiencies and the actions required to be taken by Borrower to cure the deficiencies. Upon notification of any maintenance deficiency, Borrower shall have commenced to cure such deficiency within thirty (30) days and shall diligently act to correct, remedy or cure such deficiency within no more than sixty (60) days. If the written notification states the problem is urgent relating to the public health and safety of the City of Anaheim or Governmental Lender, then Borrower shall have forty-eight (48) hours to rectify the problem. In the event Borrower does not maintain the Project Site in the manner set forth herein and in accordance with the Maintenance Standards, Governmental Lender shall have, in addition to any other rights and remedies hereunder, the right to maintain the Project Site, or to contract for the correction of such deficiencies, after written notice to Borrower, and Borrower shall be responsible for the payment of all such costs incurred by Governmental Lender.
System Maintenance The Trust understands that USBFS will perform periodic maintenance to the System(s), which may cause temporary service interruptions. To the extent possible, USBFS shall notify the Trust of all planned outages and will perform any necessary maintenance during non-business hours.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result. 38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center. 38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed. 38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties. 38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events. 38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time. 38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below. 38.7.1 AT&T TENNESSEE Disaster Recovery Plan 38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases. 38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate. 38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Maintenance Scheduling The NTO shall schedule maintenance of its facilities designated as NTO Transmission Facilities Under ISO Operational Control and schedule any outages (other than forced transmission outages) of said transmission system facilities in accordance with outage schedules approved by the ISO. The NTO shall comply with maintenance schedules coordinated by the ISO, pursuant to this Agreement, for NTO Transmission Facilities Under ISO Operational Control. The NTO shall be responsible for providing notification of maintenance schedules to the ISO for NTO Transmission Facilities Requiring ISO Notification. The NTO shall provide notification of maintenance schedules to affected Transmission Owners for NTO Transmission Facilities Requiring ISO Notification and Local Area Transmission Facilities pursuant to Section 3.5.3 of the ISO Services Tariff.
Operation and Maintenance 17.1 O&M obligations of the Concessionaire 17.1.1 During the Operation Period, the Concessionaire shall operate and maintain the Bus Terminal in accordance with this Agreement either by itself, or through the O&M Contractor and if required, modify, repair or otherwise make improvements to the Bus Terminal to comply with the provisions of this Agreement, Applicable Laws and Applicable Permits, and conform to Specifications and Standards and Good Industry Practice. The obligations of the Concessionaire hereunder shall include: (a) permitting safe, smooth and uninterrupted flow of traffic on the Bus Terminal during normal operating conditions. Buses of other state road transport corporations shall be parked inside the Bus Terminal for which no charges shall be payable to the Concessionaire and if any charges are applicable for such parking then it shall be realized by Authority only; (b) minimising incidents affecting the safety and use of the Bus Terminal by providing a rapid and effective response and maintaining liaison with emergency services of the State; (c) carrying out periodic preventive maintenance of the Bus Terminal; (d) undertaking routine maintenance including prompt repairs of ticket counters, Workshops, Authority's Office and other infrastructure as mentioned in the Operation and Maintenance Schedule; (e) undertaking major maintenance such as per the Maintenance Schedule of the major infrastructure in the Bus Terminal; (f) preventing, with the assistance of the concerned law enforcement agencies, any encroachments on the Bus Terminal; (g) protection of the environment and provision of equipment and materials therefor; (h) operation and maintenance of all communication, control and administrative systems necessary for the efficient operation of the Bus Terminal; (i) maintaining a public relations unit to interface with and attend to suggestions from the Users, passengers, government agencies, media and other agencies; (j) complying with Safety Requirements in accordance with Article 18; (k) operation and maintenance of all Project Assets diligently and efficiently and in accordance with Good Industry Practice; (l) maintaining punctuality and reliability in operating the Bus Terminal; and (m) maintaining a high standard of cleanliness and hygiene in the Bus Terminal. 17.1.2 The Concessionaire shall remove promptly from the Bus Terminal all surplus construction machinery and materials, waste materials (including hazardous materials and waste water), rubbish and other debris (including, without limitation, accident debris) and keep the Bus Terminal in a clean, tidy and orderly condition,
Maintenance and Operation Member-Generator agrees to maintain their system and facilities in accordance with applicable manufacturer's recommended maintenance schedule and standard prudent engineering practices. Member-Generator covenants and agrees to operate their system, facilities and equipment so as to minimize the likelihood for a malfunction or other disturbance, damaging or otherwise affecting or impairing Cooperative’s electrical system. Member-Generator shall comply with all applicable laws, regulations, zoning, building codes, safety rules and other environmental regulations or restrictions applicable to the design, installation, operation and maintenance of the Member-Generator's System.
Planned Maintenance (a) Subject to any modification or amendment of this Agreement made pursuant to Section 4.2(c) or Section 7.3(d), Planned Maintenance occurring during the Delivery Term shall be coordinated and scheduled in accordance with this Section 9.6. Seller shall perform all Planned Maintenance (including Major Planned Maintenance) in a manner that optimizes the generation and benefits to Buyer of the Contract Energy, Storage Energy, and other Products (e.g., during off-peak periods and low-irradiance periods) and, without limiting the foregoing, either (i) outside of Daylight Hours or (ii) during the months of October and November only, during Daylight Hours; provided, however, that the foregoing restrictions shall not apply to any Planned Maintenance that Seller is required to perform pursuant to any applicable manufacturer warranty that cannot reasonably be performed by Seller subject to such restrictions. (b) Seller shall deliver to Buyer a proposed schedule for Planned Maintenance in respect of each Contract Year (“Planned Maintenance Schedule”) no later than ninety (90) Days before the start of such Contract Year. Planned Maintenance Schedules submitted by Seller shall (i) comply with the second sentence of Section 9.6(a) and (ii) include reasonably detailed descriptions of the Planned Maintenance to be performed, the Days and times in which each type of Planned Maintenance is scheduled to be performed, the estimated amount(s) of Contract Capacity and Storage Capacity that will be unavailable due to Planned Maintenance and the total number of hours that Seller expects that the Contract Capacity and Storage Capacity will be unavailable due to Planned Maintenance. The general form for the Planned Maintenance Schedule is set forth in Schedule 9.6. (The Planned Maintenance descriptions reflected in the general form set forth in Schedule 9.6 are provided for indicative purposes only, and are not necessarily representative of the detail, time periods, or certainty required for a Planned Maintenance Schedule hereunder.) (c) Buyer shall have the right to disapprove, in its reasonable discretion (provided that Buyer shall have the right to disapprove, in its sole and absolute discretion, any Planned Maintenance proposed by Seller that is inconsistent with the terms of this Agreement), any Planned Maintenance set out in any Planned Maintenance Schedule proposed by Seller for any Contract Year, except for any Planned Maintenance that (i) is scheduled to occur outside of Daylight Hours or during Daylight Hours during the months of October and November or (ii) Seller is required to perform pursuant to any applicable manufacturer warranty and that is scheduled to occur in compliance with Section 9.6(a). If Seller submits its Planned Maintenance Schedule for a Contract Year in accordance with the requirements of this Agreement and Buyer does not disapprove of any Planned Maintenance set out in such Planned Maintenance Schedule by sixty (60) days after submission, then such Planned Maintenance Schedule shall be deemed approved. If Buyer, in the exercise of its discretion as set forth above, disapproves any Planned Maintenance in such Planned Maintenance Schedule within the applicable time period specified above after its submission, Buyer shall notify Seller and the Parties shall use Commercially Reasonable Efforts to agree upon and finalize a mutually acceptable Planned Maintenance Schedule for the applicable Contract Year. Seller shall conduct Planned Maintenance during such Contract Year only in accordance with an agreed Planned Maintenance Schedule; provided, however, that Seller may (A) move Planned Maintenance included in an agreed Planned Maintenance Schedule that is not Major Planned Maintenance, so long as such move is consistent with the terms of this Agreement (including the second sentence of Section 9.6(a)) or, with respect to Major Planned Maintenance, if such Major Planned Maintenance is scheduled to occur outside of Daylight Hours or during Daylight Hours during the months of October and November and (B) schedule and perform Planned Maintenance not reflected in the Planned Maintenance Schedule so long as such Planned Maintenance is scheduled to be performed outside of Daylight Hours or during Daylight Hours during the months of October and November and Seller provides Buyer at least two (2) weeks’ prior written notice of such Planned Maintenance; provided further that Buyer shall have the right to advise Seller of periods when Buyer prefers, based on solar irradiance, supply, market and other conditions, that any Major Planned Maintenance be deferred, and Seller shall use Commercially Reasonable Efforts to comply with such request. (d) Seller shall use Commercially Reasonable Efforts to complete any Planned Maintenance and place the Facility back into full commercial operation as soon as reasonably possible. If Seller determines that any Planned Maintenance scheduled in an agreed Planned Maintenance Schedule no longer needs to be completed or will not consume the entire time scheduled therefor in the agreed Planned Maintenance Schedule, Seller shall provide (i) a Generation Forecast to Buyer reflecting the forecasted amount of Delivered Energy during each affected interval that takes into account such change and (ii) in the case of any Major Planned Maintenance, a written notice declaring the cessation and termination of the applicable Major Planned Maintenance period (in which event, the Major Planned Maintenance period shall terminate in accordance with the terms of such Generation Forecast and written notice).
