CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
Insurance and Fingerprint Requirements Information Insurance If applicable and your staff will be on TIPS member premises for delivery, training or installation etc. and/or with an automobile, you must carry automobile insurance as required by law. You may be asked to provide proof of insurance. Fingerprint It is possible that a vendor may be subject to Chapter 22 of the Texas Education Code. The Texas Education Code, Chapter 22, Section 22.0834. Statutory language may be found at: xxxx://xxx.xxxxxxxx.xxxxx.xxxxx.xx.xx/ If the vendor has staff that meet both of these criterion: (1) will have continuing duties related to the contracted services; and (2) has or will have direct contact with students Then you have ”covered” employees for purposes of completing the attached form. TIPS recommends all vendors consult their legal counsel for guidance in compliance with this law. If you have questions on how to comply, see below. If you have questions on compliance with this code section, contact the Texas Department of Public Safety Non-Criminal Justice Unit, Access and Dissemination Bureau, FAST-FACT at XXXX@xxxxx.xxxxx.xx.xx and you should send an email identifying you as a contractor to a Texas Independent School District or ESC Region 8 and TIPS. Texas DPS phone number is (000) 000-0000. See form in the next attribute to complete entitled: Texas Education Code Chapter 22 Contractor Certification for Contractor Employees
DRUG-FREE WORKPLACE REQUIREMENTS Contractor will comply with the requirements of the Drug-Free Workplace Act of 1990 and will provide a drug-free workplace by taking the following actions: a. Publish a statement notifying employees that unlawful manufacture, distribution, dispensation, possession or use of a controlled substance is prohibited and specifying actions to be taken against employees for violations. b. Establish a Drug-Free Awareness Program to inform employees about: 1) the dangers of drug abuse in the workplace; 2) the person's or organization's policy of maintaining a drug-free workplace; 3) any available counseling, rehabilitation and employee assistance programs; and, 4) penalties that may be imposed upon employees for drug abuse violations. c. Every employee who works on the proposed Agreement will: 1) receive a copy of the company's drug-free workplace policy statement; and, 2) agree to abide by the terms of the company's statement as a condition of employment on the Agreement. Failure to comply with these requirements may result in suspension of payments under the Agreement or termination of the Agreement or both and Contractor may be ineligible for award of any future State agreements if the department determines that any of the following has occurred: the Contractor has made false certification, or violated the certification by failing to carry out the requirements as noted above. (Gov. Code §8350 et seq.)
New Hampshire Specific Data Security Requirements The Provider agrees to the following privacy and security standards from “the Minimum Standards for Privacy and Security of Student and Employee Data” from the New Hampshire Department of Education. Specifically, the Provider agrees to: (1) Limit system access to the types of transactions and functions that authorized users, such as students, parents, and LEA are permitted to execute; (2) Limit unsuccessful logon attempts; (3) Employ cryptographic mechanisms to protect the confidentiality of remote access sessions; (4) Authorize wireless access prior to allowing such connections; (5) Create and retain system audit logs and records to the extent needed to enable the monitoring, analysis, investigation, and reporting of unlawful or unauthorized system activity; (6) Ensure that the actions of individual system users can be uniquely traced to those users so they can be held accountable for their actions; (7) Establish and maintain baseline configurations and inventories of organizational systems (including hardware, software, firmware, and documentation) throughout the respective system development life cycles; (8) Restrict, disable, or prevent the use of nonessential programs, functions, ports, protocols, and services; (9) Enforce a minimum password complexity and change of characters when new passwords are created; (10) Perform maintenance on organizational systems; (11) Provide controls on the tools, techniques, mechanisms, and personnel used to conduct system maintenance; (12) Ensure equipment removed for off-site maintenance is sanitized of any Student Data in accordance with NIST SP 800-88 Revision 1; (13) Protect (i.e., physically control and securely store) system media containing Student Data, both paper and digital; (14) Sanitize or destroy system media containing Student Data in accordance with NIST SP 800-88 Revision 1 before disposal or release for reuse; (15) Control access to media containing Student Data and maintain accountability for media during transport outside of controlled areas; (16) Periodically assess the security controls in organizational systems to determine if the controls are effective in their application and develop and implement plans of action designed to correct deficiencies and reduce or eliminate vulnerabilities in organizational systems; (17) Monitor, control, and protect communications (i.e., information transmitted or received by organizational systems) at the external boundaries and key internal boundaries of organizational systems; (18) Deny network communications traffic by default and allow network communications traffic by exception (i.e., deny all, permit by exception); (19) Protect the confidentiality of Student Data at rest; (20) Identify, report, and correct system flaws in a timely manner; (21) Provide protection from malicious code (i.e. Antivirus and Antimalware) at designated locations within organizational systems; (22) Monitor system security alerts and advisories and take action in response; and (23) Update malicious code protection mechanisms when new releases are available.
Contract Work Hours and Safety Standards Act The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by: a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Insurance and Fingerprint Requirements Information Insurance If applicable and your staff will be on TIPS member premises for delivery, training or installation etc. and/or with an automobile, you must carry automobile insurance as required by law. You may be asked to provide proof of insurance. Fingerprint It is possible that a vendor may be subject to Chapter 22 of the Texas Education Code. The Texas Education Code, Chapter 22, Section 22.0834. Statutory language may be found at: xxxx://xxx.xxxxxxxx.xxxxx.xxxxx.xx.xx/ If the vendor has staff that meet both of these criterion: (1) will have continuing duties related to the contracted services; and (2) has or will have direct contact with students Then you have ”covered” employees for purposes of completing the attached form. TIPS recommends all vendors consult their legal counsel for guidance in compliance with this law. If you have questions on how to comply, see below. If you have questions on compliance with this code section, contact the Texas Department of Public Safety Non-Criminal Justice Unit, Access and Dissemination Bureau, FAST-FACT at XXXX@xxxxx.xxxxx.xx.xx and you should send an email identifying you as a contractor to a Texas Independent School District or ESC Region 8 and TIPS. Texas DPS phone number is (000) 000-0000. See form in the next attribute to complete entitled: Texas Education Code Chapter 22 Contractor Certification for Contractor Employees
Procurement of Goods and Works Except as ADB may otherwise agree, Goods and Works shall only be procured on the basis of the methods of procurement set forth below:
COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS The Contractor, it’s Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor’s obligations under this paragraph.