Notice of Delay Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
Termination Notice Except in the event of Executive's death, a termination under this Agreement shall be effected by means of a Termination Notice.
Selection Notice A Selection Notice to be effective must be:
CONVERSION NOTICE The undersigned holder of this Debenture hereby irrevocably converts the Debenture, or any portion of the principal amount at Maturity hereof (which is an integral multiple of US $1,000) below designated, into Common Shares of the Company in accordance with the terms of this Debenture, and directs that such shares, together with a Cheque in payment for any fractional shares and any Debentures representing any unconverted principal amount hereof, be delivered to and be registered in the name of the undersigned unless a different name has been indicated below. If Common Shares or Debentures are to be registered in the name of a Person other than the undersigned (which other Person the undersigned acknowledges may only be an affiliate of the undersigned), the undersigned will pay all transfer taxes, if any, payable with respect thereto. Dated: ---------------------- ----------------------------------------- ----------------------------------------- Signature(s) If Common Shares or Debentures are to be registered in If only a portion of the Debenture is to be converted, the name of a Person other than the Holder, please indicate: print such Person's name and address: ------------------------------------- Principal amount to be converted: Name US$ -------------------------------- (US$1,000 denomination or ------------------------------------- integral multiple thereof) Address ------------------------------------- Taxpayer Identification Number, if any The Debenture, if surrendered for conversion (in whole or in part) other than on an Interest Payment Date, shall be entitled to, and the Company shall make, a payment of interest, calculated in the normal course, on the outstanding principal for that portion of the period during which such principal was not converted on the next succeeding Interest Payment Date. For greater certainty, the principal amount of the Debenture that is converted shall be entitled to interest up to the Conversion Date, such interest to be paid on the next succeeding Interest Payment Date, together with interest on that portion of the principal that was not converted. The Company's delivery to the Holder of the number of Common Shares (and cash in lieu of fractions thereof) into which the Debenture is convertible will be deemed to satisfy the Company's obligation to pay the principal amount of the Debenture. The Holder shall promptly deliver to the Company and the Company, in turn, to the transfer agent of the Common Shares, notification of such Notice of Conversion at the address described in Section 105 The Debenture shall be deemed to have been converted immediately prior to the close of business on the Business Day of surrender of the Debenture for conversion (the "Conversion Date") in accordance with the foregoing provisions, and at such time the rights of the Holder, as holder of the principal amount of the Debenture so converted, shall cease, and the Person or Persons entitled to receive the Common Shares issuable upon conversion shall be treated for all purposes as the record holder or holders of such Common Shares at such time. As promptly as practicable on or after the Conversion Date, the Company shall issue and deliver to the Holder, a certificate or certificates for the number of full shares of Common Shares issuable upon conversion, together with payment in lieu of any fraction of a share, as provided in Section 1208. If the Debenture is converted in part only, upon such conversion the Company shall execute and deliver to the Holder, at the expense of the Company, a new Debenture or Debentures of authorized denominations in an aggregate principal amount equal to the unconverted portion of the principal amount of such Debenture. The Debenture may be converted in part, but only if the principal amount to be converted is any integral multiple of US$1,000.
TRANSACTION NOTICE On any Trading Day during the Commitment Period, the Company may deliver a Transaction Notice to the Sales Agent (in the case of an Issuance) or the Forward Seller and the Forward Purchaser (in the case of a Forward), subject to the satisfaction of the conditions set forth in Sections 5.01 and 5.02; provided, however, that (i) the Issuance Amount or Forward Hedge Amount, as the case may be, for each Transaction as designated by the Company in the applicable Transaction Notice shall in no event exceed $100,000,000 for any Issuance or $50,000,000 for any Forward without the prior written consent of the Sales Agent or the Forward Seller, which may be withheld in the Sales Agent’s or the Forward Seller’s sole discretion and (ii) notwithstanding anything in this Agreement or the Master Forward Confirmation to the contrary, neither the Forward Purchaser, the Sales Agent nor the Forward Seller shall have any further obligations with respect to any Transaction Notice if and to the extent the aggregate Sales Price of the Shares sold pursuant thereto, together with the aggregate Sales Price of the Shares previously sold under the Sales Agency Agreements, shall exceed the Maximum Program Amount. The Company shall have the right, in its sole discretion, to amend at any time and from time to time any Transaction Notice; provided, however, that (i) the Company may not amend the Issuance Amount or Forward Hedge Amount, as the case may be, if such amended Issuance Amount or Forward Hedge Amount, as applicable, is less than the Actual Sold Issuance Amount or Actual Sold Forward Amount, as the case may be, as of the date of such amendment; (ii) the Company shall not have the right to amend a Transaction Notice specifying that it relates to a “Forward” after the related “Supplemental Confirmation” has been delivered to the Company; and (iii) no reduction in the Floor Price shall cause any sales of Shares executed pursuant to such Transaction Notice prior to the date of receipt of such amendment to be a breach of the terms hereof.
Notice to Borrower The Agent shall promptly notify the Borrower of the terms (x) of any Money Market Quote submitted by a Bank that is in accordance with subsection (d) and (y) of any Money Market Quote that amends, modifies or is otherwise inconsistent with a previous Money Market Quote submitted by such Bank with respect to the same Money Market Quote Request. Any such subsequent Money Market Quote shall be disregarded by the Agent unless such subsequent Money Market Quote is submitted solely to correct a manifest error in such former Money Market Quote. The Agent's notice to the Borrower shall specify (A) the aggregate principal amount of Money Market Loans for which offers have been received for each Interest Period specified in the related Money Market Quote Request, (B) the respective principal amounts and Money Market Margins or Money Market Absolute Rates, as the case may be, so offered and (C) if applicable, limitations on the aggregate principal amount of Money Market Loans for which offers in any single Money Market Quote may be accepted.
Borrowing/Election Notice The Borrower shall give the Administrative Agent an irrevocable Borrowing/Election Notice of each conversion of a Floating Rate Loan into a Eurodollar Rate Loan or continuation of a Eurodollar Rate Loan not later than 11:00 a.m. (Chicago time) three (3) Business Days prior to the date of the requested conversion or continuation, specifying: (i) the requested date (which shall be a Business Day) of such conversion or continuation; (ii) the amount and Type of the Loan to be converted or continued; and (iii) the amount of Eurodollar Rate Loan(s) into which such Loan is to be converted or continued, and the duration of the Interest Period applicable thereto.
Termination Upon Notice This Agreement may be terminated at any time without cause by either party giving the other party one hundred eighty (180) days written notice.
Notice to NYSE Parent shall, to the extent possible, give the NYSE not less than ten (10) days’ advance notice of the Record Date in compliance with Rule 10b-17 under the Exchange Act.
Events Requiring Notice to the Representative The Company shall use its best efforts to cause the Registration Statement to remain effective with a current prospectus for at least nine (9) months after the Applicable Time, and shall notify the Representative immediately and confirm the notice in writing: (i) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (ii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (iv) of the receipt of any comments or request for any additional information from the Commission; and (v) of the happening of any event during the period described in this Section 3.5 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement, the Pricing Disclosure Package or the Prospectus untrue or that requires the making of any changes in (a) the Registration Statement in order to make the statements therein not misleading, or (b) in the Pricing Disclosure Package or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company shall make every reasonable effort to obtain promptly the lifting of such order.
