Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.
Acceptance of the Work 19.1 No act of, or failure to act by, the Owner or the OWNER'S REPRESENTATIVE during the course of the Work, nor any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the Final Payment by the Owner to Contractor. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof.
19.2 Contractor agrees to guarantee all work under this Contract for a period of one year from the date of Final Payment by the Owner or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required under terms of Owner’s conditional acceptance of elements of the Work the Owner deems marginally substandard. If any unsatisfactory condition or damage develops within the time of this guarantee period due to materials or workmanship that are defective, inferior, or not in accordance with the Contract, as reasonably determined by the Owner or the OWNER’S REPRESENTATIVE, then the Contractor shall, when notified by the Owner or OWNER’S REPRESENTATIVE, immediately place such guaranteed Work in a condition satisfactory to the Owner or OWNER’S REPRESENTATIVE. Such guarantee shall be in addition to any implied warranty under law or other manufacturer’s or product supplier’s warranty. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.
Offer and Acceptance of Weekend Overtime (a) The Employer is committed to providing reasonable notice to Employees of an offer / cancellation of weekend overtime. To this end, notice will generally be provided prior to the normal meal break on Thursday. Where the Employer is unable to give such notice the Employer may offer I cancel such overtime by notifying affected Employees before the finish time of ordinary hours on Friday.
(b) Overtime will be offered on a work required basis.
(c) Employees who accept an offer of weekend overtime will be obliged to attend. However, Employees may find themselves unable to fulfil their commitment to attend site. Such Employees will notify the Employer before the planned finishing time on Friday.
(d) An Employee may refuse to work weekend overtime if the requirement to do so is plainly unreasonable having regard to:
(i) the hours of work that will be worked by that Employee in the week of the weekend overtime;
(ii) the amount of weekend overtime worked by the Employee within the previous six weeks;
(iii) the Employee’s family responsibilities; and
(iv) any other special circumstances peculiar to the Employee.
Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.
Acceptance of the Terms of Use These terms of use are entered into by and between you and Tribal Convenience Store Association ("Company", "we" or "us"). The following terms and conditions (these "Terms of Use") govern your access to and use of the Company’s website, xxxx://xxx.xxxxxxxxxxxxx.xxx, including any content, functionality and services offered on or through the website (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use. If you do not want to agree to these Terms of Use, you must not access or use the Website. This Website is offered and available only to users who are 18 years of age or older, and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:
1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or
2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
Delivery and Acceptance of the Manuscript The Author shall deliver the Contribution to the Editor (or, if requested by the Publisher, to the Publisher) on or before Delivery Date (the “Delivery Date”) electronically in the Publisher's standard requested format or in such other form as may be agreed in writing with the Publisher. The Author shall retain a duplicate copy of the Contribution. The Contribution shall be in a form acceptable to the Publisher (acting reasonably) and in line with the instructions contained in the Publisher’s guidelines as provided to the Author by the Publisher. The Author shall provide at the same time, or earlier if the Publisher reasonably requests, any editorial, publicity or other information (and in such form or format) reasonably required by the Publisher. The Publisher may exercise such additional quality control of the manuscript as it may decide at its sole discretion including through the use of plagiarism checking systems and/or peer review by internal or external reviewers of its choice. If the Publisher decides at its sole discretion that the final manuscript does not conform in quality, content, structure, level or form to the stated requirements of the Publisher, the Publisher shall be entitled to terminate this Agreement in accordance with the provisions of this Clause. The Author must inform the Publisher at the latest on the Delivery Date if the sequence of the naming of any co-authors entering into this Agreement shall be changed. If there are any changes in the authorship (e.g. a co-author joining or leaving), then the Publisher must be notified by the Author in writing immediately and the Parties will amend this Agreement accordingly. The Publisher shall have no obligation to consider publication under this Agreement in the absence of such agreed amendment. If the Author fails to deliver the Contribution in accordance with the provisions of this Clause above by the Delivery Date (or within any extension period given by the Publisher at its sole discretion) or if the Author (or any co-author) dies or becomes incapacitated or otherwise incapable of performing the Author’s obligations under this Agreement, the Publisher shall be entitled to either: (a) elect to continue to perform this Agreement in accordance with its terms and the Publisher may commission an appropriate and competent person (who, in the case of co-authors having entered into this Agreement, may be a co-author) to complete the Contribution; or (b) terminate this Agreement with immediate effect by written notice to the Author or the Author's successors, in which case all rights granted by the Author to the Publisher under this Agreement shall revert to the Author/Author's successors (subject to the provisions of the Clause "Termination"). The Author agrees, at the request of the Publisher, to execute all documents and do all things reasonably required by the Publisher in order to confer to the Publisher all rights intended to be granted under this Agreement. The Author warrants that the Contribution is original except for any excerpts from other works including pre-published illustrations, tables, animations, text quotations, photographs, diagrams, graphs or maps, and whether reproduced from print or electronic or other sources ("Third Party Material") and that any such Third Party Material is in the public domain (or otherwise unprotected by copyright/other rights) or has been included with written permission from or on behalf of the rights holder (and if requested in a form prescribed or approved by the Publisher) at the Author's expense unless otherwise agreed in writing, or is otherwise used in accordance with applicable law. On request from the Publisher, the Author shall in writing indicate the precise sources of these excerpts and their location in the manuscript. The Author shall also retain the written permissions and make them available to the Publisher on request.
Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
Acceptance of Work The completion of the Work shall be subject to acceptance by NYSERDA in writing of all deliverables as defined in Exhibit A, Statement of Work.
NON-ACCEPTANCE OF SETTLEMENT AGREEMENT If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.
