STANDARD DESIGN. 1. The structural floor system of the Building is designed to accommodate up to one hundred (100) pounds per square foot, including eight of partitions and up to seven (7) pounds of ceiling and suspended mechanical equipment load.
STANDARD DESIGN Sample Clauses
Related to STANDARD DESIGN
Project Design Applicants must design a project that provides access to health services to enable eligible women and men experiencing health needs to secure and maintain safe and accessible quality screening and diagnostic services, comprehensive family planning, and/ or other women’s health services. A. Applicants are encouraged to emphasize the following components in the design of their projects. Projects must: 1. Use a collaborative approach to maximize existing community resources and avoid duplication of effort; 2. Enhance systems and local processes to make it easier for people to transition to, from, and between services; 3. Address barriers to ensure services are accessible to people regardless of setting or location; and 4. Promote improvement and positively impact health and well-being through coordinated service delivery. B. To be effective, services and activities provided or made available as part of the Proposed Project should have policies and procedures in place and include with the application as an attachment that: 1. Delineate the timely provision of services; 2. Deem Client eligibility and service provision as soon as possible and no later than 30 calendar days from initial request; 3. Require staff to assess and prioritize Client needs; 4. Implement with model fidelity to an evidence-based program or based upon best available research; 5. Plan in partnership with the person and are inclusive; 6. Provide in an environment that is most appropriate and based on a person’s preference including reasonable clinic/reception wait times that are not a barrier to care; 7. Provide referral sources for Clients that cannot be served or receive a specific service; 8. Are culturally and linguistically sensitive; 9. Tailor services to a person’s unique strengths and needs; 10. Manage funds to ensure established Clients continuity of care throughout budget year; 11. Continue to provide services to established Clients after allocated funds are expended; 12. Have processes to identify and eliminate possible barriers to care; 13. Do not deny services due to inability to pay; 14. Have appropriate key personnel and required staff to meet the medical and health needs of Clients; 15. Bill services appropriately and timely through TMHP; 16. Effectively communicate and document information related to health care needs with next steps available to Client; 17. Establish outreach and education plan for the community; and 18. Outline successful delivery of direct clinical services to Clients By submitting an Application under this RFA, the Applicant certifies that Applicant has or will have at time of grant award services, policies, or procedures that conform with the requirements in this section as applicable. HHSC, in its sole discretion, may request to review relevant documentation during the project period as necessary to ensure program fidelity.
Schematic Design See Section 2, Part 1, Article 2.1.4, Paragraph 2.1.4.2.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
Standard Services As long as Tenant is not in default under any of the provisions of this Lease, Landlord shall cause the Leased Premises (in accordance with Section 10.3 below) and the public and common areas of the Building, (and the Project Common Areas), including the lobbies, elevators, stairs, corridors and rest rooms, to be maintained in reasonably good order and condition consistent with the operation and maintenance of the Building as a first-class office building in downtown Bellevue, except for damage occasioned by any act or omission of Tenant or Tenant's officers, contractors, agents, invitees, licensees or employees, the repair of which shall be paid for by Tenant ,so long as damage occasioned by other tenants and their officers, contractors, agents, invitees, licensees or employees, is paid for by such other tenants. From 7:00 a.m. to 6:00 p.m. on weekdays, excluding legal holidays, and from 8:00 a.m. to noon on Saturdays ("Regular Business Hours"), Landlord shall furnish the Leased Premises with electricity for lighting and operation of low power usage office machines, water, heat, air conditioning and elevator service as is customary and anticipated by tenants in a first-class office building (the "Standard Services"). During all other hours, Landlord shall furnish the Standard Services, including elevator service as reasonably required to provide access to the Leased Premises, except for heat and air conditioning and lighting. If requested by Tenant, Landlord shall furnish heat and air conditioning and lighting at times other than Regular Business Hours and the cost of such services, as established by Landlord (which in no event shall exceed Landlords' actual cost of such services), shall be paid by Tenant in the same manner as provided in Section 4.1 above. Landlord also shall provide lamp replacement service for Building Standard fluorescent light fixtures (but not for any specialty lighting installed by Tenant), toilet room supplies, window washing at reasonable intervals and customary building janitorial service in the Leased Premises consistent with those services in other first-class office buildings as part of the Standard Services, although no janitorial service shall be provided for Saturdays, Sundays or legal holidays. The cost and expense of any janitorial or other services provided or caused to be provided by Landlord to Tenant in addition to the services ordinarily provided Building tenants or is excessive relative to services provided to other tenants in the Building generally, Tenant shall reimburse Landlord upon demand for the additional cost resulting from such services, which shall be paid by Tenant in the same manner as provided for payment in Section 4.1 above. Standard Services shall not include any security services exclusively for Tenant within the Leased Premises. General security services will be provided in a manner consistent with the nature of the Project, and its cost will be allocated as a Building and/or Project Operating Cost. Landlord has not and does not make any representations to Tenant and assumes no responsibility to Tenant that the security services that are provided by Landlord will be effective in preventing any harm, both physical and economic, to Tenant or any of Tenant's employees or invitees. The HVAC system that Landlord shall install in the Building is generally described in Schedule D-1 and, among other things, shall allow temperature adjustments to be made in the Leased Premises on a zone by zone basis on each floor. Tenant shall pay any and all costs required to implement the features of the system by which Tenant may make temporary adjustments on a zone by zone basis on each floor . Any services provided by Landlord under this Section 6.4 shall be applied consistently and in a nondiscriminatory manner.
Program Design The County Human Resources Department will operate a Catastrophic Leave Bank which is designed to assist any County employee who has exhausted all paid accruals due to a serious or catastrophic illness, injury, or condition of the employee or family member. The program establishes and maintains a Countywide bank wherein any employee who wishes to contribute may authorize that a portion of his/her accrued vacation, compensatory time, holiday compensatory time or floating holiday be deducted from those account(s) and credited to the Catastrophic Leave Bank. Employees may donate hours either to a specific eligible employee or to the bank. Upon approval, credits from the Catastrophic Leave Bank may be transferred to a requesting employee's sick leave account so that employee may remain in paid status for a longer period of time, thus partially ameliorating the financial impact of the illness, injury, or condition. Catastrophic illness or injury is defined as a critical medical condition, a long-term major physical impairment or disability which manifests itself during employment.
System and Data Access Services a. System. Subject to the terms and conditions of this Addendum and solely for the purpose of providing access to Fund Data as set forth herein, State Street hereby agrees to provide the Fund, or certain third parties approved by State Street that serve as the Fund`s investment advisors, investment managers or fund accountants (the "Fund Accountants") or as the Fund`s independent auditors (the "Auditor"), with access to State Street`s Multicurrency HORIZONR Accounting System and the other information systems described in Attachment A (collectively, the "System") on a remote basis solely on the computer hardware, system software and telecommunication links described in Attachment B (the "Designated Configuration") or on any designated substitute or back-up equipment configuration consented to in writing by State Street, such consent not to be unreasonably withheld.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
Exclusive Services Executive shall at all times faithfully, industriously and to the best of his or her ability, experience and talent perform to the satisfaction of the Board and the CEO all of the duties that may be assigned to Executive hereunder and shall devote substantially all of his or her productive time and efforts to the performance of such duties. Subject to the terms of the Employee Confidentiality and Invention Assignment Agreement referred to in Section 5(b), this shall not preclude Executive from devoting time to personal and family investments or serving on community and civic boards, or participating in industry associations, provided such activities do not interfere with his or her duties to the Company, as determined in good faith by the CEO. Executive agrees that he or she will not join any boards, other than community and civic boards (which do not interfere with his or her duties to the Company), without the prior approval of the CEO.
ROADWAY DESIGN MISCELLANEOUS (ROADWAY)
