Content of Bidding Documents 8.1 The set of bidding documents comprises the documents listed in the table below and addenda issued in accordance with Clause 10. Invitation for Bids
Contractor’s Documents Any licensing and maintenance agreement, or any order-specific agreement or document, including any pre-installation, linked or “click through” agreement that is allowed by, referenced within or incorporated within the Contract whenever the Contract is used for a State procurement, whether directly by the Contractor or through a Contractor’s agent, subcontractor or reseller, is agreed to only to the extent the terms within any such agreement or document do not conflict with the Contract or applicable Minnesota or Federal law, and only to the extent that the terms do not modify, diminish or derogate the terms of the Contract or create an additional financial obligation to the State. Any such agreement or document must not be construed to deprive the State of its sovereign immunity, or of any legal requirements, prohibitions, protections, exclusions or limitations of liability applicable to this Contract or afforded to the State by Minnesota law. A State employee’s decision to choose “accept” or an equivalent option associated with a “click- through” agreement does not constitute the State’s concurrence or acceptance of terms, if such terms are in conflict with this section. State Audits.
Regulatory Requirements and Governing Law 43 14.1 Regulatory Requirements. 43 14.2 Governing Law 44 ARTICLE 15. NOTICES 44 15.1 General. 44 15.2 Xxxxxxxx and Payments. 44 15.3 Alternative Forms of Notice 44 15.4 Operations and Maintenance Notice 44 ARTICLE 16. FORCE MAJEURE 45 16.1 Force Majeure 45 ARTICLE 17. DEFAULT 45 17.1 Default. 45 ARTICLE 18. INDEMNITY, CONSEQUENTIAL DAMAGES AND INSURANCE 46 18.1 Indemnity. 46 18.2 No Consequential Damages. 47 18.3 Insurance 47 ARTICLE 19. ASSIGNMENT 49 19.1 Assignment. 49 ARTICLE 20. SEVERABILITY 49 20.1 Severability. 49 ARTICLE 21. COMPARABILITY 50 21.1 Comparability. 50 ARTICLE 22. CONFIDENTIALITY 50 22.1 Confidentiality. 50 ARTICLE 23. ENVIRONMENTAL RELEASES 53 23.1 Developer and Connecting Transmission Owner Notice 53 ARTICLE 24. INFORMATION REQUIREMENT 53 24.1 Information Acquisition. 53 24.2 Information Submission by Connecting Transmission Owner 54 24.3 Updated Information Submission by Developer 54 24.4 Information Supplementation 54 ARTICLE 25. INFORMATION ACCESS AND AUDIT RIGHTS 55 25.1 Information Access. 55 25.2 Reporting of Non-Force Majeure Events. 55 25.3 Audit Rights. 56 25.4 Audit Rights Periods. 56 25.5 Audit Results. 56 ARTICLE 26. SUBCONTRACTORS 56 26.1 General. 56 26.2 Responsibility of Principal. 57 26.3 No Limitation by Insurance 57 ARTICLE 27. DISPUTES 57 27.1 Submission 57 27.2 External Arbitration Procedures. 57 27.3 Arbitration Decisions. 58 27.4 Costs. 58 27.5 Termination 58 ARTICLE 28. REPRESENTATIONS, WARRANTIES AND COVENANTS 58 28.1 General. 58 ARTICLE 29. MISCELLANEOUS 59 29.1 Binding Effect. 59 29.2 Conflicts. 59 29.3 Rules of Interpretation 59 29.4 Compliance 60 29.5 Joint and Several Obligations. 60 29.6 Entire Agreement. 60 29.7 No Third Party Beneficiaries. 60 29.8 Waiver 60 29.9 Headings. 61 29.10 Multiple Counterparts. 61 29.11 Amendment. 61 29.12 Modification by the Parties. 61 29.13 Reservation of Rights. 61 29.14 No Partnership 62 29.15 Other Transmission Rights. 62 Appendices STANDARD LARGE GENERATOR INTERCONNECTION AGREEMENT THIS STANDARD LARGE GENERATOR INTERCONNECTION AGREEMENT (“Agreement”) is made and entered into this 17th day of April 2013, by and among Erie Boulevard Hydropower, LP (a limited partnership subsidiary of Brookfield Renewable Power), a company organized and existing under the laws of the State of New York (“Developer” with a Large Generating Facility), the New York Independent System Operator, Inc., a not-for-profit corporation organized and existing under the laws of the State of New York (“NYISO”), and Niagara Mohawk Power Corporation d/b/a National Grid, a corporation organized and existing under the laws of the State of New York (“Connecting Transmission Owner”). Developer, the NYISO, or Connecting Transmission Owner each may be referred to as a “Party” or collectively referred to as the “Parties.”
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Certification Regarding Prohibition of Boycotting Israel (Tex Gov. Code 2271) If (a) Vendor is not a sole proprietorship; (b) Vendor has ten (10) or more full-time employees; and (c) this Agreement or any agreement with a TIPS Member under this procurement has value of $100,000 or more, the following certification shall apply; otherwise, this certification is not required. Vendor certifies, where applicable, that neither the Vendor, nor any affiliate, subsidiary, or parent company of Vendor, if any, boycotts Israel, and Vendor agrees that Vendor and Vendor Companies will not boycott Israel during the term of this Agreement. For purposes of this Agreement, the term “boycott” shall mean and include refusing to deal with, terminating business activities with, or otherwise taking any action that is intended to penalize, inflict economic harm on, or limit commercial relations with Israel, or with a person or entity doing business in Israel or in an Israeli-controlled territory but does not include an action made for ordinary business purposes. When applicable, does Vendor certify? Yes
Formation of the contract i. A contract for the Services will be formed between you and us, once you have given us a signed, fully completed, Admissions form, Contract and a £15 booking fee, and we have confirmed to you in writing that your application for a place has been successful.
Compliance with Federal and State Work Authorization and Immigration Laws The Contractor and all subcontractors, suppliers and consultants must comply with all federal and state work authorization and immigration laws, and must certify compliance using the form set forth in Section 7 (“Georgia Security and Immigration Compliance Act Affidavits”). The required certificates must be filed with the Owner and copied maintained by the Contractor as of the beginning date of this contract and each subcontract, supplier contract, or consultant contract, and upon final payment to the subcontractor or consultant. State officials, including officials of the Georgia Department of Audits and Accounts, officials of the Owner, retain the right to inspect and audit the Project Site and employment records of the Contractor, subcontractors and consultants without notice during normal working hours until Final Completion, and as otherwise specified by law and by Rules and Regulations of the Georgia Department of Audits and Accounts.
Clarification of Bidding Documents 10.1 The prospective bidder requiring any clarification of the bidding documents may notify the Employer in writing or by cable (hereinafter the term cable is deemed to include telex, email and facsimile) at the Employer’s mailing address indicated in the Bidding Data.
Amendment of Bidding Documents 10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by issuing addenda.
Bidding Documents The Construction Documents, the Invitation to Bid, the Instructions to Bidders, the Bid Form, and all Addenda, upon which the Bidder submits a Bid.
