Subcontractor Caused Delays Sample Clauses

Subcontractor Caused Delays. If the progress of the Work or the Project is delayed, disrupted, hindered, obstructed, or interfered with by any fault or neglect, or act or failure to act by the Subcontractor or any of its employees, tier-subcontractors or suppliers and the delay causes additional cost, expense, liability or damage to any other “Project Team Member” (including legal fees and disbursements incurred by any of them, whether incurred in defending claims arising from the delay or in seeking reimbursement and indemnity from Subcontractor and its surety (if applicable)), or any damages or additional costs or expenses for which the Contractor may or will become liable, then Subcontractor and its surety (if applicable) will be financially responsible. Subcontractor’s financial responsibility will include all costs for necessary acceleration and recovery as well as damages assessed against Contractor under the Contract and any additional compensation paid by Contractor to other Project Team Members. Subcontractor will indemnify and hold the Contractor and Owner harmless from all alleged or actual claims, liabilities, and damages arising out of or resulting from any delay, interference or disruption to the critical path of the most current approved Project Schedule or to any other Project Team Members’ time, that is caused by Subcontractor’s or its tier-subcontractors’ or suppliers’ negligent acts or omissions in accordance with Article 9.
Sample 1
AutoNDA by SimpleDocs
Subcontractor Caused Delays. If Subcontractor should default in performance of the Work or should otherwise commit any act which causes delay to the completion of the Project, Subcontractor shall be liable for all losses, costs, expenses, liabilities and damages, including consequential damages and liquidated damages, sustained by Contractor, or for which Contractor may be liable to Owner or any other party because of Subcontractor's default.
Sample 1

Related to Subcontractor Caused Delays

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination for Force Majeure In the event of a force majeure that lasts longer than thirty (30) days from the date that a Party claiming relief due to the force majeure event gives notice to the other Party, the Party not claiming relief under the force majeure event may terminate this Agreement upon written notice to the other Party. For the avoidance of doubt, the COVID-19 pandemic does not constitute a force majeure event.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • TERMINATION FOR CAUSE BY CONTRACTOR 4.06.1 Contractor may terminate its performance under this Agreement only if the City defaults and fails to cure the default after receiving written notice of it. Default by the City occurs if the City fails to perform one or more of its material duties under this Agreement. If a default occurs and Contractor wishes to terminate the Agreement, then Contractor must deliver a written notice to the Director describing the default and the proposed termination date. The date must be at least 30 days after the Director receives the notice. Contractor, at its sole option, may extend the proposed termination date to a later date. If the City cures the default before the proposed termination date, then the proposed termination is ineffective. If the City does not cure the default before the proposed termination date, then Contractor may terminate its performance under this Agreement on the termination date

  • H7 Force Majeure H7.1 Neither Party, shall be liable to the other Party for any delay in performing, or failure to perform, its obligations under the Contract (other than a payment of money) to the extent that such delay or failure is a result of Force Majeure. Notwithstanding the foregoing, each Party shall use all reasonable endeavours to continue to perform its obligations under the Contract for the duration of such Force Majeure. However, if such Force Majeure prevents either Party from performing its material obligations under the Contract for a period in excess of six (6) Months, either Party may terminate the Contract with immediate effect by notice in writing.

  • Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.

  • Termination of Work Notwithstanding any other term of this Agreement, each of the parties shall be entitled at any time to terminate the Marine Spill Response Services, or any portion thereof, being provided under this Agreement in any given case by giving notice to the other. Upon such notice being provided, Applicable Response Organization shall cease to provide the Marine Spill Response Services or any portion thereof, and shall carry out any required demobilization activities, and Owner shall pay all outstanding Applicable Response Organization Fees and Taxes.

  • Termination by Contractor Contractor may, at its option, terminate this Contract upon the failure of MPS to pay any amount, which may become due hereunder for a period of sixty (60) days following submission of appropriate billing and supporting documentation. Upon said termination, Contractor shall be paid the compensation due for all services rendered through the date of termination including any retainage.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!