Subcontractor Indemnity Clause Samples

The Subcontractor Indemnity clause requires the subcontractor to compensate and protect the contractor from losses, damages, or legal claims arising from the subcontractor’s work or actions. Typically, this means if the subcontractor’s employees cause injury, property damage, or violate laws while performing their duties, the subcontractor must cover any resulting costs or liabilities faced by the contractor. This clause serves to allocate risk by ensuring that the party most directly responsible for certain actions—the subcontractor—bears the financial consequences, thereby protecting the contractor from unforeseen liabilities.
POPULAR SAMPLE Copied 4 times
Subcontractor Indemnity. Except as otherwise provided in this Contract, all Subcontracts between the Contractor and its Subcontractors, shall contain an agreement by the Subcontractor to indemnify, defend and hold harmless the Commonwealth, its officers, agents, and employees, and each and every Enrollee from any liability whatsoever arising in connection with this Contract for the payment of any debt of or the fulfillment of any obligation of the Subcontractor. Each such Subcontractor shall further covenant and agree that in the event of a breach of the Subcontract by the Contractor, termination of the Subcontract, or Insolvency of the Contractor, each Subcontractor shall provide all services and fulfill all of its obligations pursuant to the Subcontract for the remainder of any month for which the Department has made payments to the Contractor, and shall fulfill all of its obligations respecting the transfer of Enrollees to other Providers, including record maintenance, access and reporting requirements all such covenants, agreements, and obligations of which shall survive the termination of this Contract and any Subcontract.
View SourceView Similar (12)
Subcontractor Indemnity. The Indemnity will apply to any Subcontractor approved and Credentialed by the HSP, for the duration of the approved Subcontract.
View SourceView Similar (4)
Subcontractor Indemnity. (a) The Subcontractor must indemnify the Contractor, its officers, employees and agents from and against all costs (including reasonable legal fees), losses, claims, damages and liabilities arising from or in connection with: (i) the personal injury, illness or death of any person; (ii) any loss of or damage to any property of any person, including the Site or the Subcontract Works; (iii) any acts, defaults or omissions of a Lower Tier Subcontractor (including their employees and agents); (iv) any failure to comply with clause 6, 9 or 10; (v) the Contractor not being able to fully recover because of the operation of provisions of Proportionate Liability Legislation; (vi) the Subcontractor Works not being in accordance with the requirements of the Subcontract; (vii) suspension by a Lower Tier Subcontractor under the Security of Payment Act; payment by the Contractor of a Lower Tier Subcontractor pursuant to clause 31.3; and any payment of a Lower Tier Subcontractor by the Contractor of an adjudicated amount identified on an adjudication certificate issued by an authorised nominating authority, arising out of or in connection with the Subcontract, but the indemnity will be proportionately reduced to the extent that a negligent act or omission of the Contractor directly contributes to the injury, death, loss or damage. (b) Each indemnity of the Subcontractor is a continuing obligation, separate and independent from the other obligations of the Subcontractor (including any obligation to pay liquidated damages) and survives the termination or expiration of this Subcontract. (c) It is not necessary for the Contractor to incur expense or to make any payment before enforcing a right of indemnity conferred by the Subcontract. (d) The Subcontractor shall pay on demand any amount it is obliged to pay to the Contractor under any indemnity in this Subcontract.
View SourceView Similar (2)
Subcontractor Indemnity. Design/Builder shall require each of its Subcontractors to comply with the requirements of this Article 7 related to indemnifying, holding harmless, and defending Public Agency, except to the extent Public Agency agrees in writing to apply a different set of standards or requirements to a particular Subcontractor.
View SourceView Similar (3)
Subcontractor Indemnity. ESCO shall require each of its Subcontractors to comply with the requirements of this Article related to indemnifying, holding harmless, and defending the District.
View Source
Subcontractor Indemnity. To the fullest extent permitted by Law, Subcontractor shall indemnify, defend and hold harmless the Contractor Indemnified Parties from and against any and all loss, damage, expense and liability, including fines, penalties, court costs and reasonable attorneys’ fees (collectively, “Liabilities”) incurred by any Contractor Indemnified Party in connection with or arising from any third-party claim for physical or other damage to or physical destruction of property or bodily injury to any Person in connection with or related to (a) any breach or violation of or default under this Agreement or any Applicable Legal Requirements by, or (b) the fault, willful misconduct, or negligent acts or omissions of, in each case of (a) and (b), to the extent of the fault, act or omission of the Subcontractor or its agents, Subcontractors or employees or others under its control, provided, however, that in no event shall Subcontractor be obligated under this section to the extent such Liabilities arise due to the negligence or willful misconduct of the Contractor Indemnified Parties or any third party.
View Source
Subcontractor Indemnity. IBM shall defend, at its expense, Empire and its respective Affiliates and their respective officers, directors, employees, agents, successors and assigns, against any and all non-Affiliated third party claims arising from any claim or action by IBM's subcontractors arising out of IBM's breach or violation of IBM's subcontracting arrangements.
View Source
Subcontractor Indemnity. The Subcontractor indemnifies Honeywell and each of its officers, employees and agents (collectively, the "Indemnitees") against any loss, costs, damage, liability or expenses which they may incur or suffer arising out of or in connection with any act, breach, omission or default of the Subcontractor ("Loss"). The liability of the Subcontractor under the above paragraph will be reduced to the extent that Honeywell’s negligence or a breach of this Subcontract by Honeywell has caused or contributed to the loss, cost, damage, liability or expense. The Subcontractor indemnifies the Indemnitees against: 1) liquidated damages for delay payable by Honeywell under the Main Contract; and 2) other damages payable by Honeywell under or in connection with the Main Contract in consequence of Honeywell failing to achieve completion under the Main Contract by the required date for completion, 3) arising out of or in connection with any act or omission of the Subcontractor. The Subcontractor acknowledges that the rate of liquidated damages payable by Honeywell under the Main Contract is set out in the Subcontract Particulars. The Subcontractor’s liability to indemnify the Indemnitees under this Section will be reduced proportionally to the extent that any of the costs, expenses, losses or damages suffered or incurred by Honeywell as referred to in this Section is caused by a breach of this Subcontract by Honeywell or by Honeywell’s negligence.
View Source

Related to Subcontractor Indemnity

  • Lessor Indemnification Lessor and its successors and assigns shall indemnify, defend, reimburse and hold Lessee, its employees and lenders, harmless from and against any and all environmental damages, including the cost of remediation, which existed as a result of Hazardous Substances on the Premises prior to the Start Date or which are caused by the gross negligence or willful misconduct of Lessor, its agents or employees. Lessor's obligations, as and when required by the Applicable Requirements, shall include, but not be limited to, the cost of investigation, removal, remediation, restoration and/or abatement, and shall survive the expiration or termination of this Lease.

  • Tenant’s Indemnification Tenant shall indemnify Landlord and Landlord’s managing agent from any and all claims, losses, liabilities, costs, expenses and damages, including attorneys’ fees, costs of testing and remediation costs, incurred by Landlord in connection with any breach by Tenant of its obligations under this Article 15. The covenants and obligations under this Article 15 shall survive the expiration or earlier termination of this Lease.

  • IPR Indemnity 23.2.1 The Supplier shall ensure and procure that the availability, provision and use of the Goods and/or Services and the performance of the Supplier's responsibilities and obligations hereunder shall not infringe any Intellectual Property Rights of any third party. 23.2.2 The Supplier shall at all times during and after the Framework Period, on written demand indemnify the Authority against all Losses incurred by, or awarded against the Authority (whether before or after the making of the demand pursuant to the indemnity hereunder) arising from an IPR Claim. 23.2.3 If an IPR Claim is made, or the Supplier anticipates that an IPR Claim might be made, the Supplier may, at its own expense and sole option, either: (a) procure for the Authority the right to continue using the relevant item which is subject to the IPR Claim; or (b) replace or modify the relevant item with non-infringing substitutes provided that: (i) the performance and functionality of the replaced or modified item is at least equivalent to the performance and functionality of the original item; (ii) the replaced or modified item does not have an adverse effect on any other Goods and/or Services; (iii) there is no additional cost to the Authority; and (iv) the terms and conditions of this Framework Agreement shall apply to the replaced or modified Goods and/or Services. 23.2.4 If the Supplier elects to procure a licence in accordance with Clause 23.2.3(a) or to modify or replace an item pursuant to Clause 23.2.3(b), but this has not avoided or resolved the IPR Claim, then: (a) the Authority may terminate this Framework Agreement by written notice with immediate effect; and (b) without prejudice to the indemnity set out in Clause 23.2.2, the Supplier shall be liable for all reasonable and unavoidable costs of the modified or substitute items and/or services including the additional costs of procuring, implementing and maintaining the substitute items.

  • Subcontractor Insurance In accord with Good Utility Practice, each Interconnected Entity shall require each of its subcontractors to maintain and provide evidence of insurance coverage of types, and in amounts, commensurate with the risks associated with the services provided by the subcontractor. Bonding of contractors or subcontractors shall be at the hiring Interconnected Entity’s discretion, but regardless of bonding, the hiring principal shall be responsible for the performance or non- performance of any contractor or subcontractor it hires.

  • Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined). 22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees), (a) based on allegations that, if true, would establish (i) the Indemnifying Party’s breach of this Agreement; (ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct; (iii) the Indemnifying Party’s negligent or willful misconduct or omissions; (iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party; (v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or (vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or (b) that arises out of: (i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement; (ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement; (iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement; (iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or (v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)). 22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section. 22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.