Substantial Completion and Contract Completion Sample Clauses

Substantial Completion and Contract Completion. FAR 52.211-10, Commencement, Prosecution, and Completion of Work, FAR 52.211-12, Liquidated Damages (Construction), and GSAR 552.246-72, Final Inspection and Tests, are supplemented as follows: (1) For the purposes of FAR 52.211-10, Commencement, Prosecution and Completion of Work, and FAR 52.211-12, Liquidated Damages (Construction), the Work shall be deemed complete when it is “Substantially Complete.” The Work shall be deemed "Substantially Complete" if and only if the Contractor has completed the Work and related Contract obligations in accordance with the Contract Documents, such that the Government may enjoy the intended access, occupancy, possession, and use of the entire Work without impairment due to incomplete or deficient work, and without interference from the Contractor's completion of remaining work or correction of deficiencies in completed work. In no event shall the Work be deemed Substantially Complete if all fire and life safety systems are not tested and accepted by the Authority Having Jurisdiction, where such acceptance is required under the Contract. (2) With reasonable advance notice, the Contractor shall submit to the Contracting Officer a written proposal recommending a Substantial Completion date (Notice of Substantial Completion). The Contracting Officer shall conduct inspections and make a determination of Substantial Completion within a reasonable time. If the Contracting Officer takes exception to the Notice of Substantial Completion, the Contractor shall be entitled to a written notice of conditions precluding determination of Substantial Completion. (3) The Contractor shall only be entitled to an extension of time to address such conditions if, and to the extent that, the Contracting Officer provides notice of such conditions more than thirty
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Substantial Completion and Contract Completion. (1) The Work shall be deemed "Substantially Complete" if and only if the Contractor has completed the Work and related Contract obligations in accordance with the Contract Documents, such that the Government may enjoy the intended access, occupancy, possession, and use of the entire Work without impairment due to incomplete or deficient work, and without interference from the Contractor's completion of remaining work or correction of deficiencies in completed work. In no event shall the Work be deemed Substantially Complete if all fire and life safety systems are not tested and accepted by the Authority Having Jurisdiction, where such acceptance is required under the Contract. (2) With reasonable advance notice, the Contractor shall submit to the Contracting Officer a written proposal recommending a Substantial Completion date (Notice of Substantial Completion). The Contracting Officer shall conduct inspections and make a determination of Substantial Completion within a reasonable time. If the Contracting Officer takes exception to the Notice of Substantial Completion, the Contractor shall be entitled to a written notice of conditions precluding determination of Substantial Completion. (3) The Contractor shall only be entitled to an extension of time to address such conditions if, and to the extent that, the Contracting Officer provides notice of such conditions more than thirty
Sample 1

Related to Substantial Completion and Contract Completion

  • Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.

  • Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.

  • COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project (a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020. (b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control. (c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.

  • Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.

  • Final Completion The full and final completion of all Work in accordance with the Contract Documents.

  • Commencement and Completion The Work shall commence on _______________, 20__ and shall be complete in accordance with this Agreement without delay on ______________, 20__. The term “day”, used throughout this Agreement, refers to calendar days. Contractor shall not be entitled to any additional compensation for any Permitted Delays. If this Agreement is not signed and returned to the Owner before any work commences, this Agreement will be considered as accepted as presented to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!