Common use of SUPERINTENDENCE AND SUPERVISION Clause in Contracts

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1. County’s instructions are to be given through Consultant, which instructions Contractor must strictly and promptly follow in every case. Contractor shall keep on the Project a full-time, competent, English-speaking superintendent and any necessary assistants, all of whom must be satisfactory to Consultant. The superintendent shall not be changed except with the written consent of Consultant, unless the superintendent proves to be unsatisfactory to Contractor and ceases to be in its employ. The superintendent shall represent Contractor; all instructions given to the superintendent shall be as binding as if given to Contractor, and will be confirmed in writing by Consultant upon the written request of Contractor. Contractor shall provide efficient supervision of the Work, using its best skill and attention. 14.2. On a daily basis, Contractor’s superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors at the Project site; visitors to the Project site, including representatives of County, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site and shall be available at all times for inspection and copying by County and Consultant. 14.3. The Contract Administrator, Contractor, and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeks. Consultant shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If Contractor, in the course of performing the Work, finds any discrepancy between this Contract and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contract, it shall be Contractor’s duty to immediately inform Consultant, in writing, and Consultant will promptly review same. Any Work done after such discovery, until authorized, will be done at Contractor’s sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contract. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1. CountyTown’s instructions are to be given through Consultant, which instructions Contractor must strictly and promptly follow in every case. Contractor shall keep on the Project a full-time, competent, English-speaking superintendent and any necessary assistants, all of whom must be satisfactory to Consultant. The superintendent shall not be changed except with the written consent of Consultant, unless the superintendent proves to be unsatisfactory to Contractor and ceases to be in its employ. The superintendent shall represent Contractor; all instructions given to the superintendent shall be as binding as if given to Contractor, and will be confirmed in writing by Consultant upon the written request of Contractor. Contractor shall provide efficient supervision of the Work, using its best skill and attention. 14.2. On a daily basis, Contractor’s superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors at the Project site; visitors to the Project site, including representatives of CountyTown, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site and shall be available at all times for inspection and copying by County Town and Consultant. 14.3. The Contract Administrator, Contractor, and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeks. Consultant shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If Contractor, in the course of performing the Work, finds any discrepancy between this Contract and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contract, it shall be Contractor’s duty to immediately inform Consultant, in writing, and Consultant will promptly review same. Any Work done after such discovery, until authorized, will be done at Contractor’s sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contract. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.11. County’s instructions The orders of the County are to be given through Consultantthe Project Manager, which instructions Contractor must are to be strictly and promptly follow followed in every case. Contractor CONTRACTOR shall keep on the Project during its progress, a full-time, competent, English-English speaking superintendent superintendent, and any necessary assistants, all of whom must be satisfactory to Consultantthe Project Manager. The superintendent shall not be changed except with the written consent of Consultantthe Project Manager, unless the superintendent proves to be unsatisfactory to Contractor CONTRACTOR and ceases to be in its employ. The superintendent shall represent Contractor; CONTRACTOR and all instructions directions given to the superintendent shall be as binding as if given to Contractor, CONTRACTOR and will be confirmed in writing by Consultant the Project Manager upon the written request of ContractorCONTRACTOR. Contractor CONTRACTOR shall provide give efficient supervision of to the Work, using its best skill and attention. 14.22. On a daily basisDaily, Contractor’s CONTRACTOR's superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work work being performed; quantities of materials, quantities of labor, names of personnel, equipment and Subcontractors subcontractors at the Project site; visitors to the Project site, including representatives of the County, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site and shall be available at all times for inspection and copying by County and Consultantthe County. This log shall be submitted electronically, in PDF format via e-mail, to the Project Manager each project day. 14.33. The Contract Administrator, Contractor, CONTRACTOR and Consultant the Project Manager shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) CONTRACT ADMINISTRATOR, during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two weeks (2) weeks14 days). Consultant The Project Manager shall publish, keep, and distribute minutes and any comments thereto of each such meeting. These meetings may be postponed, cancelled, or waived with the Project Manager’s written approval. 14.44. If ContractorCONTRACTOR, in the course of performing the Work, finds any discrepancy between this the Contract Documents and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contractthe plans, it shall be Contractor’s CONTRACTOR's duty to immediately inform Consultantthe Project Manager, in writing, and Consultant the Project Manager will promptly review the same. Any Work done after such discovery, until authorized, will be done at Contractor’s CONTRACTOR's sole risk, without entitlement to reimbursement or compensation. 14.55. Contractor CONTRACTOR shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contractthe Contract Documents. Contractor CONTRACTOR shall be solely responsible for the means, methods, techniques, sequences, and procedures of constructionconstruction and the consequences of each. Damages and losses incurred to tangible County property by CONTRACTOR’s means and methods shall be the sole responsibility of the CONTRACTOR to fix and/or remunerate. 6. For every PO placed with the CONTRACTOR through this Contract, a project superintendent employed full-time by the CONTRACTOR shall be on the project site at all times while work is being performed. The project superintendent shall be the sole point of contact with the Project Manager. Two-way communication shall only be between these two persons so as to prevent any miscommunications and to maintain control of the project scope, schedule, and budget. The Project Manager, or a delegate, shall reserve the right to order the CONTRACTOR to stop work if the CONTRACTOR’s project superintendent is not on the project site full-time.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1The Design-Build Firm shall keep the Contract under his own control and it shall be its responsibility to see that the Work is properly supervised and carried on faithfully and efficiently. County’s The Design-Build Firm shall supervise the Work personally and shall have a competent, English-speaking superintendent, or representative who shall be on the site of the Project at all working hours, and who shall have full authority by the Design-Build Firm to direct the performance of the Work and make arrangements for all necessary materials, equipment, and labor without delay. The orders of the City are given through the Project Manager, which instructions are to be given through Consultant, which instructions Contractor must strictly and promptly follow followed in every case. Contractor Design-Build Firm shall keep on the Project during its progress, a full-time, competent, English-time competent English speaking superintendent and any necessary assistants, all of whom must be satisfactory to ConsultantProject Manager. The superintendent shall not be changed except with the written consent of ConsultantProject Manager, unless the superintendent proves to be unsatisfactory to Contractor Design-Build Firm and ceases to be in its employ. The superintendent shall represent Contractor; Design-Build Firm and all instructions directions given to the superintendent shall be as binding as if given to Contractor, Design-Build Firm and will be confirmed in writing by Consultant Project Manager upon the written request of ContractorDesign-Build Firm. Contractor Design-Build Firm shall provide give efficient supervision of to the Work, using its best skill and attention. 14.2. On a daily basis, Contractor’s The Project Manager shall be provided telephone number(s) for the superintendent where the superintendent can be contacted during normal working hours as well as after hours for emergencies. The Design-Build Firm's superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors Sub Design-Build Firm s and Subconsultants at the Project siteProject(s) site(s); visitors to the Project site, including representatives of Countythe City, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in indelible ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site Project(s) site(s) and shall be available at all times for inspection and copying by County and Consultant. 14.3Project Manager. The Contract AdministratorProject Manager, Contractor, Design-Build Firm and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) Project Manager, during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeksoutstanding issues. Consultant The Design-Build Firm shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If ContractorDesign-Build Firm, in the course of performing the Work, finds any discrepancy between this the Contract Documents and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contractthe Plans, it shall be Contractor’s Design-Build Firm's duty to immediately inform Project Manager and Consultant, in writing, and Consultant Project Manager or Consultant, will promptly review the same. Any All Work done after performed as a result of such discovery, until authorized, will be done at Contractor’s Design-Build Firm's sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor Design-Build Firm shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contractthe Contract Documents. Contractor Design-Build Firm shall be solely responsible for the means, methods, techniques, sequences, sequences and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1The Design-Build Firm shall keep the Contract under his own control and it shall be its responsibility to see that the Work is properly supervised and carried on faithfully and efficiently. County’s The Design-Build Firm shall supervise the Work personally and shall have a competent, English-speaking superintendent, or representative who shall be on the site of the Project at all working hours, and who shall have full authority by the Design-Build Firm to direct the performance of the Work and make arrangements for all necessary materials, equipment, and labor without delay. The orders of the City are given through the Project Manager, which instructions are to be given through Consultant, which instructions Contractor must strictly and promptly follow followed in every case. Contractor Design-Build Firm shall keep on the Project during its progress, a full-time, competent, English-time competent English speaking superintendent and any necessary assistants, all of whom must be satisfactory to ConsultantProject Manager. The superintendent shall not be changed except with the written consent of ConsultantProject Manager, unless the superintendent proves to be unsatisfactory to Contractor Design-Build Firm and ceases to be in its employ. The superintendent shall represent Contractor; Design-Build Firm and all instructions directions given to the superintendent shall be as binding as if given to Contractor, Design-Build Firm and will be confirmed in writing by Consultant Project Manager upon the written request of ContractorDesign-Build Firm. Contractor Design-Build Firm shall provide give efficient supervision of to the Work, using its best skill and attention. 14.2. On a daily basis, Contractor’s The Project Manager shall be provided telephone number(s) for the superintendent where the superintendent can be contacted during normal working hours as well as after hours for emergencies. The Design-Build Firm's superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors and Subconsultants at the Project siteProject(s) site(s); visitors to the Project site, including representatives of Countythe City, ConsultantDesign Criteria Professional, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in indelible ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site Project(s) site(s) and shall be available at all times for inspection and copying by County and Consultant. 14.3Project Manager. The Contract AdministratorProject Manager, Contractor, Design-Build Firm and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) Project Manager, during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeksoutstanding issues. Consultant The Design-Build Firm shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If ContractorDesign-Build Firm, in the course of performing the Work, finds any discrepancy between this the Contract Documents and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contractthe Plans, it shall be Contractor’s Design-Build Firm's duty to immediately inform Project Manager and Consultant, in writing, and Consultant Project Manager or Consultant, will promptly review the same. Any All Work done after performed as a result of such discovery, until authorized, will be done at Contractor’s Design-Build Firm's sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor Design-Build Firm shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contractthe Contract Documents. Contractor Design-Build Firm shall be solely responsible for the means, methods, techniques, sequences, sequences and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1The Design-Build Firm shall keep the Contract under his own control and it shall be its responsibility to see that the Work is properly supervised and carried on faithfully and efficiently. County’s The Design-Build Firm shall supervise the Work personally and shall have a competent, English-speaking superintendent, or representative who shall be on the site of the Project at all working hours, and who shall have full authority by the Design-Build Firm to direct the performance of the Work and make arrangements for all necessary materials, equipment, and labor without delay. The orders of the City are given through the Project Manager, which instructions are to be given through Consultant, which instructions Contractor must strictly and promptly follow followed in every case. Contractor Design-Build Firm shall keep on the Project during its progress, a full-time, competent, English-time competent English speaking superintendent and any necessary assistants, all of whom must be satisfactory to ConsultantProject Manager. The superintendent shall not be changed except with the written consent of ConsultantProject Manager, unless the superintendent proves to be unsatisfactory to Contractor Design-Build Firm and ceases to be in its employ. The superintendent shall represent Contractor; Design-Build Firm and all instructions directions given to the superintendent shall be as binding as if given to Contractor, Design-Build Firm and will be confirmed in writing by Consultant Project Manager upon the written request of ContractorDesign-Build Firm. Contractor Design-Build Firm shall provide give efficient supervision of to the Work, using its best skill and attention. 14.2. On a daily basis, Contractor’s The Project Manager shall be provided telephone number(s) for the superintendent where the superintendent can be contacted during normal working hours as well as after hours for emergencies. The Design-Build Firm's superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors Sub Design-Build Firm s and Subconsultants at the Project siteProject(s) site(s); visitors to the Project site, including representatives of Countythe City, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in indelible ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site Project(s) site(s) and shall be available at all times for inspection and copying by County and Consultant. 14.3Project Manager. The Contract AdministratorProject Manager, Contractor, Design-Build Firm and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) Project Manager, during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeksoutstanding issues. Consultant The Design-Build Firm shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If ContractorDesign-Build Firm, in the course of performing the Work, finds any discrepancy between this the Contract Documents and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contractthe Plans, it shall be Contractor’s Design-Build Firm's duty to immediately inform Project Manager and Consultant, in writing, and Consultant Project Manager or Consultant, will promptly review the same. Any All Work done after performed as a result of such discovery, until authorized, will be done at Contractor’s Design-Build Firm's sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor Design-Build Firm shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contractthe Contract Documents. Contractor Design- Build Firm shall be solely responsible for the means, methods, techniques, sequences, sequences and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1. CountyMunicipality’s instructions are to be given through Consultant, which instructions Contractor must strictly and promptly follow in every case. Contractor shall keep on the Project a full-time, competent, English-speaking superintendent and any necessary assistants, all of whom must be satisfactory to Consultant. The superintendent shall not be changed except with the written consent of Consultant, unless the superintendent proves to be unsatisfactory to Contractor and ceases to be in its employ. The superintendent shall represent Contractor; all instructions given to the superintendent shall be as binding as if given to Contractor, and will be confirmed in writing by Consultant upon the written request of Contractor. Contractor shall provide efficient supervision of the Work, using its best skill and attention. 14.2. On a daily basis, Contractor’s superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors at the Project site; visitors to the Project site, including representatives of CountyMunicipality, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site and shall be available at all times for inspection and copying by County Municipality and Consultant. 14.3. The Contract Administrator, Contractor, and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeks. Consultant shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If Contractor, in the course of performing the Work, finds any discrepancy between this Contract and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contract, it shall be Contractor’s duty to immediately inform Consultant, in writing, and Consultant will promptly review same. Any Work done after such discovery, until authorized, will be done at Contractor’s sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contract. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1. County’s instructions The orders of County are to be given through Consultant, which instructions Contractor must are to be strictly and promptly follow followed in every case. Contractor shall keep on the Project during its progress, a full-timefull‐time, competent, English-speaking English‐speaking superintendent and any necessary assistants, all of whom must be satisfactory to Consultant. The superintendent shall not be changed except with the written consent of Consultant, unless the superintendent proves to be unsatisfactory to Contractor and ceases to be in its employ. The superintendent shall represent Contractor; Contractor and all instructions directions given to the superintendent shall be as binding as if given to Contractor, Contractor and will be confirmed in writing by Consultant upon the written request of Contractor. Contractor shall provide give efficient supervision of to the Work, using its best skill and attention. 14.2. On a daily basisDaily, Contractor’s superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors subcontractors at the Project site; visitors to the Project site, including representatives of County, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; , any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site and shall be available at all times for inspection and copying by County and Consultant. 14.3. The Contract Administrator, Contractor, and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) , during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeks. Consultant shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If Contractor, in the course of performing prosecuting the Work, finds any discrepancy between this Contract and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contract, it shall be Contractor’s duty to immediately inform Consultant, in writing, and Consultant will promptly review the same. Any Work done after such discovery, until authorized, will be done at Contractor’s sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contract. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1. County’s instructions 16.1 The orders of the City are to be given through Consultantthe Project Manager, which whose instructions Contractor must are to be strictly and promptly follow followed in every case. The Contractor shall keep maintain a competent resident supervisor, who shall serve as the Designated Representative, and any necessary assistants on the Project a full-timesite throughout the duration of the Project. The Designated Representative shall serve as the Contractor’s Superintendent onsite and shall be responsible for continuous field supervision, competentcoordination, English-speaking superintendent and any necessary assistants, all completion of whom the work. The Designated Representative must be satisfactory able to Consultantcommunicative effectively and be onsite a minimum of eight (8) hours per day, Monday through Friday (excluding holidays), and when any work or deliveries are occurring. The superintendent Designated Representative shall not be changed except with the written consent of Consultantthe Project Manager, unless the superintendent Designated Representative proves to be unsatisfactory to the Contractor and ceases to be in its employ. The superintendent Designated Representative shall represent the Contractor; , and all instructions direction given to the superintendent Designated Representative shall be as binding as if given to the Contractor, and . Directions will be confirmed in writing by Consultant upon to the Contractor. Other directions will be so confirmed on written request of Contractor. Contractor shall provide efficient supervision of the Work, using its best skill and attentionin each case. 14.2. On 16.2 The Designated Representative shall, on a daily basis, Contractor’s superintendent shall recordprepare and keep a log setting forth, at a minimum, the following information in a bound logminimum for each day: the day; date; weather conditions and how any weather condition conditions affected progress of the Workwork; time of commencement of Work work performed; equipment utilized for the daywork; the Work being performed; materials, labor, personnel, any idle equipment and Subcontractors at the Project sitereasons for idleness; visitors to the Project site, including representatives of County, Consultant, or regulatory representatives; labor utilized for the work; and any event that caused or contributed a delay materials delivered to the critical path of the Project; any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by ConsultantProject site. The daily log shall be kept on or accessible from available for inspection by the Project site and shall be available Manager at all times during the Project. Electronic logging is permitted provided the City has full access to such logs and the logs are provided in PDF format or via Procore software at any time when requested by the City. If the Contractor utilizes Procore software, access to same must be provided to the City for inspection and copying by County and Consultantup to twelve (12) months following Final Completion. 14.3. The Contract Administrator, Contractor, and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeks. Consultant shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If Contractor16.3 If, in the course of performing the WorkProject, the Contractor finds any discrepancy between this the Contract Documents and the physical conditions of the locality, or any errorserrors or omissions in the Contract Documents, omissions, or discrepancies in this Contractincluding drawings (plans) and specifications, it shall be the Contractor’s duty to immediately inform Consultant, the Project Manager in writing, and Consultant the Project Manager will promptly review verify the same. Any Work work done after such discovery, until authorizedbut before being remedied, will shall be done at the Contractor’s 's sole risk, without entitlement to reimbursement or compensation. 14.5. 16.4 The Contractor shall supervise coordinate, supervise, and direct the Work Project competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work Project in accordance with this Contractthe Contract Documents. The Contractor shall be solely responsible for the means, methods, techniques, safety, sequences, and procedures of construction. The Contractor shall give efficient supervision to the work using its best skill, attention, and judgment.

SUPERINTENDENCE AND SUPERVISION. ‌ 14.1. County’s instructions are to The orders of County areto be given through Consultant, which instructions Contractor must are to be strictly and promptly follow followed in every case. Contractor shall keep on the Project during its progress, a full-full- time, competent, English-speaking superintendent and any necessary assistants, all of whom must be satisfactory to Consultant. The superintendent shall not be changed except with the written consent of Consultant, unless the superintendent proves to be unsatisfactory to Contractor and ceases to be in its employ. The superintendent shall represent Contractor; Contractor and all instructions directions given to the superintendent shall be as binding as if given to Contractor, Contractor and will be confirmed in writing by Consultant upon the written request of Contractor. Contractor shall provide give efficient supervision of to the Work, using its best skill and attention. 14.2. On a daily basisDaily, Contractor’s superintendent shall record, at a minimum, the following information in a bound log: the day; date; weather conditions and how any weather condition affected progress of the Work; time of commencement of Work for the day; the Work being performed; materials, labor, personnel, equipment and Subcontractors subcontractors at the Project site; visitors to the Project site, including representatives of County, Consultant, or regulatory representatives; any event that caused or contributed a delay to the critical path of the Project; , any special or unusual conditions or occurrences encountered; and the time of termination of Work for the day. All information shall be recorded in the daily log in ink, unless otherwise approved by Consultant. The daily log shall be kept on or accessible from the Project site and shall be available at all times for inspection and copying by County and Consultant. 14.3. The Contract Administrator, Contractor, and Consultant shall meet at least every two (2) weeks (or as otherwise determined by the Contract Administrator) , during the course of the Work to review and agree upon the Work performed to date and to establish the controlling items of Work for the next two (2) weeks. Consultant shall publish, keep, and distribute minutes and any comments thereto of each such meeting. 14.4. If Contractor, in the course of performing prosecuting the Work, finds any discrepancy between this Contract and the physical conditions of the locality, or any errors, omissions, or discrepancies in this Contract, it shall be Contractor’s duty to immediately inform Consultant, in writing, and Consultant will promptly review the same. Any Work done after such discovery, until authorized, will be done at Contractor’s sole risk, without entitlement to reimbursement or compensation. 14.5. Contractor shall supervise and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with this Contract. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction.