Supplier Obligations 7.1 The Supplier shall: 7.1.1 at all times allocate sufficient resources to supply the Services in accordance with the Contract; 7.1.2 provide and fulfil any ancillary or incidental service, function or responsibility not specified in the Service Specification where such service, function or responsibility is necessary for the proper performance of the relevant Services; 7.1.3 obtain, and maintain throughout the duration of the Contract, all the consents, approvals, licences and permissions (statutory, regulatory, contractual or otherwise) it may require and which are necessary for the provision of the Services or performance of any other obligation under this Contract; 7.1.4 ensure the Supplier Assets used in the performance of the Services will be free of all encumbrances (except as agreed in writing with the Authority); 7.1.5 ensure that in the performance of its obligations under the Contract it does not disrupt the operations of each Commissioning Body and their respective Personnel; 7.1.6 ensure that any documentation, information and training provided to each Commissioning Body under this Contract (including in relation to the use of the Website) is comprehensive, accurate and prepared in accordance with Good Industry Practice; 7.1.7 co-operate with the Other Supplier(s) and provide reasonable information (including any documentation), advice and assistance in connection with the Services to the Other Supplier(s) including to enable such Other Supplier(s) to provide services to the respective Commissioning Bodies and, on the expiry or termination of this Contract for any reason, to enable the timely transition of the Services (or any of them) to the respective Commissioning Bodies and/or to any Replacement Supplier; 7.1.8 to the extent it is legally able to do so, hold on trust for the sole benefit of the Authority, all warranties and indemnities provided by third parties or any Sub- contractor in respect of any Deliverables and/or the Services and, where any such warranties are held on trust, at its cost enforce such warranties in accordance with any reasonable directions that the Authority may notify from time to time to the Supplier; 7.1.9 unless it is unable to do so, assign to the Authority on the Authority’s written request and at the cost of the Supplier any such warranties and/or indemnities as are referred to in Clause 7.1.8; 7.1.10 provide each Commissioning Body with such advice and assistance as that Commissioning Body may reasonably require during the Contract Period in respect of the supply of the Services; 7.1.11 gather, collate and provide such information and co-operation as the Authority may reasonably request for the purposes of ascertaining the Supplier’s compliance with its obligations under the Contract; 7.1.12 notify the Authority of any circumstances suggesting that a change of Control of the Supplier is planned, in contemplation or has taken place; 7.1.13 notify the Authority in writing of any material detrimental change in the financial standing and/or any change in the credit rating of the Supplier; 7.1.14 subject to Clause 33.6, notify the Authority in writing within ten (10) Working Days of their occurrence, of any actions, suits or proceedings or regulatory investigations before any court or administrative body or arbitration tribunal pending or, to its knowledge, threatened against it that might affect its ability to perform its obligations under the Contract; and 7.1.15 ensure that neither it, nor any of its Affiliates or Personnel, bring any Commissioning Body into disrepute by engaging in any act or omission which is reasonably likely to diminish the trust that the public places in that Commissioning Body, regardless of whether or not such act or omission is related to the Supplier’s obligations under this Contract.
Customer Obligations 41.1. The Customer undertakes to use the Services strictly in accordance with the Contract and such other conditions as may be notified in writing to the Customer by Comtact from time to time and in accordance with the relevant provisions of the Communications Xxx 0000 with any other applicable laws and regulations, any directions given by the Director General of the office of Telecommunications or other competent authority. 41.2. The Customer will ensure that neither the Customer nor anyone under their control may use the Services:- o as a means of communication for a purpose other than that for which the Services are provided or in a manner in which constitutes a violation or infringement of the rights of any other party; o to make offensive, indecent, menacing, nuisance or hoax calls or calls of a defamatory character or fraudulently or in connection with a criminal offence. 41.3. The Customer hereby indemnifies and shall keep indemnified Comtact against all liabilities, claims, damages, losses and expenses arising from any breach of the Customer’s obligations in clause 41.2 and against any claim which is made against Comtact and/or the TSP because the Services are misused in any way by the Customer. Comtact or TSP reserve the right to take further action as specified in clause 46. 41.4. In respect of LCR Services the Customer is responsible for checking that the Customer is not currently in a contract with any other supplier(s) before changing over the line rental or LCR services to Comtact. Comtact will not be liable for any cancellation charges or other fees charged by the Customer’s previous supplier. 41.5. The Customer will comply with current regulations for NGNs which includes but is not limited to the following: o the Customer will provide the caller pricing information for each number wherever the number is printed or published. o the Customer will notify callers of undue delays between a call being connected and the caller accessing the service o where required the Customer will obtain prior permission for premium rate numbers 41.6. Comtact cannot be held responsible for any costs, consequential or otherwise, incurred by the Customer in preparation for the commencement of services until such time that Comtact confirms the activation of NGN number(s). The Customer should not undertake any marketing activities or publication of numbers until an order confirmation has been received from Comtact.
Contractor Obligations After receipt of the Notice of Termination and except as otherwise directed by the State, the Contractor shall immediately proceed to: a. To the extent specified in the Notice of Termination, stop work under the Contract on the date specified. b. Place no further orders or subcontracts for materials, services, and/or facilities except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated. c. Terminate and cancel any orders or subcontracts for related to the services, except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated. d. Transfer to the State all completed or partially completed plans, drawings, information, and other property which, if the Contract had been completed, would be required to be furnished to the State. e. Take other action as may be necessary or as directed by the State for the protection and preservation of the property related to the contract which is in the possession of the contractor and in which the State has or may acquire any interest. f. Make available to the State all cost and other records relevant to a determination of an equitable settlement.
USER OBLIGATIONS As a user of the Website or Services, You may be asked to register with Us. When You do so, You will choose a user identifier, which may be Your email address or another term, as well as a password. You may also provide personal information, including, but not limited to, Your name. You are responsible for ensuring the accuracy of this information. This identifying information will enable You to use the Website and Services. You must not share such identifying information with any third party, and if You discover that Your identifying information has been compromised, You agree to notify Us immediately in writing. Email notification will suffice. You are responsible for maintaining the safety and security of Your identifying information as well as keeping Us apprised of any changes to Your identifying information. Providing false or inaccurate information, or using the Website or Services to further fraud or unlawful activity is grounds for immediate termination of this Agreement.
Developer Obligations In accordance with applicable NYISO requirements, Developer shall maintain satisfactory operating communications with Connecting Transmission Owner and NYISO. Developer shall provide standard voice line, dedicated voice line and facsimile communications at its Large Generating Facility control room or central dispatch facility through use of either the public telephone system, or a voice communications system that does not rely on the public telephone system. Developer shall also provide the dedicated data circuit(s) necessary to provide Developer data to Connecting Transmission Owner and NYISO as set forth in Appendix D hereto. The data circuit(s) shall extend from the Large Generating Facility to the location(s) specified by Connecting Transmission Owner and NYISO. Any required maintenance of such communications equipment shall be performed by Developer. Operational communications shall be activated and maintained under, but not be limited to, the following events: system paralleling or separation, scheduled and unscheduled shutdowns, equipment clearances, and hourly and daily load data.
Our Obligations Some obligations placed on us under this contract may be carried out by another person. If an obligation is placed on us to do something under this contract, then: (a) we are taken to have complied with the obligation if another person does it on our behalf; and (b) if the obligation is not complied with, we are still liable to you for the failure to comply with this contract.
CONTRACTOR OBLIGATION Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records provided to Enterprise Services that Contractor believes are statutorily exempt from disclosure and identify the precise statutory basis for exemption from disclosure. In addition, if, in Contractor’s judgment, certain portions of such records are not statutorily exempt from disclosure but are sensitive because particular portions of Contractor’s records (NOT including pricing) include highly confidential, proprietary, or trade secret information (or the equivalent) that Contractor protects through the regular use of confidentiality or similar agreements and routine enforcements through court enforcement actions, Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records that include such sensitive information.
Your Obligations You will: (a) at all times throughout the duration of the terms of this Exhibit ensure that all publicity, signage, and/or promotional material you issue, or have issued on your behalf, in respect of or in connection with the EMV PSP Service complies in all respects with the Codes of Practice and includes information which will enable the Service User to ascertain prior to use the charge which is payable for the purchase of the Offering. You will not in any publicity or other promotional activity state or imply any approval by NCR Voyix or its third-party suppliers of the Offering in any way without the prior written approval of a duly authorized officer of NCR Voyix or its third-party suppliers, as applicable; (b) ensure that before you make the Offering available to the Service User all such rights, authorizations, licenses, exemptions, consents and permissions have been obtained or granted and all such requirements of law or of any other competent authority or public body have been complied with as are necessary or prudent in connection with the Offering. You will at all times throughout the duration of the terms of this Exhibit maintain in full force and effect all such rights, authorizations, licenses, consents and permissions and comply with all such requirements; (c) provide to NCR Voyix such assistance and/or information as NCR Voyix or its third- party supplier may from time to time reasonably demand in order to comply with all or any requirements and conditions at any time and from time to time imposed by applicable law or regulation with respect to the EMV PSP Service; (d) undertake not to disconnect or interfere with the operation of the Terminals or the EMV PSP Service and will use your best efforts to prevent such disconnection or interference by a third party except where explicitly agreed in writing between NCR Voyix and you; (e) report to NCR Voyix any abuse or threatened abuse or loss of the EMV PSP Service or any factors affecting the performance of the EMV PSP Service as soon as practicable after you become aware of such abuse, loss or performance factors; (f) not use the EMV PSP Service in any manner whatsoever which constitutes a violation of any applicable law or regulation or which may cause NCR Voyix or its third-party supplier to be subject to any investigation, prosecution or legal action. NCR Voyix reserves the right to terminate this Exhibit or the Agreement with immediate effect in the event that you breach this subsection (f); (g) except where otherwise agreed between the parties in writing, be responsible for the installation of the EMV PSP Service, which without limiting the foregoing, will include you setting up a Merchant Account with an approved Merchant Acquiring Bank, the linking of all Terminals to the Public System and the provision, installation and maintenance of a suitable method for delivering the Card information to the EMV PSP Service and thereafter the maintenance of all links and any costs associated with the foregoing; and acknowledge that NCR Voyix and its third-party suppliers do not have access to your Merchant Account and that it is therefore your responsibility to reconcile the payments and debits being made into your Merchant Account with the Transactions and/or Refunds processed by the EMV PSP Service in connection with the Service. In the event that you identify a discrepancy you must notify NCR Voyix as soon as reasonably practical. NCR Voyix and its third-party suppliers will have no liability for discrepancies which have occurred more than 14 days prior to the date any such problem is notified to them.
SUPPLIER’S OBLIGATIONS 4.2.1 The Supplier shall be responsible for implementing all the necessary resources for the performance of its obligations under the Contract, with the exception of those specifically mentionedin the Contractas beingunder the responsibility of the Purchaser. The Supplier shall haveall of thematerials andtoolsneededfor theperformanceof the Contractandshall allocate qualified staff in sufficient numbers to perform the Contract within the contractual deadline. The Supplier shall ensureappropriatepersonneltraining andqualification andsubmitanyproof relating to such qualification upon Purchaser’s request. Within seven (7) days, at the latest, of the Contract coming into force, the Supplier shall appoint a staff member as aprojectmanager and shall inform the Purchaser accordingly. The project manager shall plan, coordinate and monitor all the Supply’sneedsin compliancewith the Contractandthe Good Industry Practices andshall be the Supplier’s contact person for the Purchaser. 4.2.2 The Supplier shall request from the Purchaser in a timely manner, any approvals and instructions needed for the correct performance of the Contract. If applicable, the Purchaser shall grant access to the site where the Supply is to be performed (the “Site”) and /or make available to the Supplier the materials and/or perform the works identified in the Contract. 4.2.3 The Supplier shall promptly remedy or shall ensure that its subcontractors promptly remedy any defects relating to the Supply noted during the abovementioned visits as well as any defect notified to it by the Purchaser concerning its performance. 4.2.4 The Supplier shall ensure that the Supply provided are fit for the purposes that may reasonablybeinferred from the Contractandinaccordancewith the timetableforperformance defined in the Contract. In any event the Supplier commitshimself toachieveperformance and results stipulated in the Contract. The performance deadlinesmay only be extended or reduced through an amendment to the Contract, in accordance with the provisions of Article 5.1. The Supply shall be delivered in a state of full completion with the complete Documentation associated therewith as well as all instructions, recommendations and other indications necessary in order for them to be used correctly and under the appropriate safety conditions. “Documentation” shall mean any operation and maintenance manuals, drawings, calculations, technical data, logic diagrams, progress reports, quality documentation, conformity certificates, test reports, bill of lading, certificates of origin, export control classification list number as per any applicable export regulation - such as (i) the European Council Regulation 428/2009 (as amended), (ii) the U.S. Export Administration Regulations (“EAR”), (iii) percentage of U.S. origin content, (iv) U.S. Export Control Classification Number (“ECCN”), (v) U.S. Munitions List category (“USML”),(vi) (if applicable) export authorizations and licenses, and/or (vii) Harmonized Tariff Code - and any such other documents required under the Contract and/or applicable laws. The Supplier shall also furnish such programme of design, manufacture and delivery as the Purchaser may reasonably require. If so required by the Purchaser, the Supplier shall submit any such Documentation to the Purchaser with sufficient time for review and approval. Where the Documentation provided by the Supplier is not compliant with Purchaser’s contractual requirements, the Supplier must make the necessary modifications, and indemnify the Purchaser for any costs, liabilities or penalties incurred by the Purchaser due to the delays or non-compliance in Documentation delivered by the Supplier and shall not be entitled to an adjustment of the delivery schedule in case of any revision.
Service Provider Obligations Service Provider shall make the Software and the Services required for provisioning the Software (Software and Services hereinafter together and individually may also be referred to as “Service” or “Services”) available to Customer as described in the Services Description and in the Services Specific Terms (together hereinafter referred to as “Services Description”) referenced in the Order Forms and according to the terms and conditions of this Agreement. Service Provider may amend the Services from time to time, provided that such amendments shall not materially diminish the overall Service. Service Provider aims to provide the Software access to Customer within two (2) working days upon the Effective Date, unless otherwise set forth in the Services Description. The Software may consist of a web application provided to Customer in form of a software as a service solution and a mobile application to be installed by Customer on its mobile device. The agreed scope and quality of the Services is exclusively set forth in the Services Description. Public statements concerning the Service made by Service Provider or its agents will only take form when expressively confirmed by Service Provider in writing. Notwithstanding section 7.1, information and specifications contained within the Services Description shall not qualify as warranty or guarantee with regards to the Service’s quality or as any other kind of guarantee, unless they have been confirmed as such by Service Provider in writing. Service Provider may update and improve the Services from time to time; any such Updates, meaning software that remedies "Defects" (as defined in section 7.4) in the Services and/or may include minor improvements of the Services, are included in the Agreement. In addition to Updates, Service Provider may offer Upgrades and/or Add-On Services to the Services, where “Upgrades” mean new capabilities or functionalities of the Services and “Add-On Services” either mean (i) new and/or additional functionality packages in form of separate modules to the Services, or (ii) integrations or connection applications with other Hilti or third party software applications. Upgrades and Add-On Services are only subject to the Agreement, if ordered separately and paid for by Customer, where additional terms and conditions may apply.
