SUSPENSION OF WORK DUE TO UNFAVORABLE CONDITIONS Sample Clauses

SUSPENSION OF WORK DUE TO UNFAVORABLE CONDITIONS. 12.2.100 If, in the judgment of the Authority, the Contractor is taking undue risk of damage to any part of a structure or installation by proceeding with the work during unfavorable weather or other conditions, then the Authority may suspend the work temporarily, either wholly or in part for such periods as are necessary. In case of such suspension, a proper extension of time will be allowed as provided herein, but no allowance will be made to the Contractor for any expense or damages resulting from the suspension. The failure of the Authority to suspend the work does not relieve the Contractor of its responsibility to perform the work in accordance with the Contract Documents.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to SUSPENSION OF WORK DUE TO UNFAVORABLE CONDITIONS

  • Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.

  • Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds. Contractor further certifies under pains and penalties of perjury that, as of the date this contract amendment is signed, Contractor is not presently debarred, suspended, nor named on the State’s debarment list at: xxxx://xxx.xxxxxxx.xxx/purchasing-contracting/debarment Sole Source Contract for Services. This Contract results from a “sole source” procurement under State of Vermont Administrative Bulletin 3.5 process and Contractor hereby certifies that it is and will remain in compliance with the campaign contribution restrictions under 17 V.S.A. § 2950. This document consists of 2 pages. Except as modified by this Amendment No. 3, all provisions of the Contract remain in full force and effect. The signatures of the undersigned indicate that each has read and agrees to be bound by this Amendment to the Contract. Revision Date: 05/30/2019 STATE OF VERMONT XXXXX ELECTRIC By: Name: Xxxxxxxx Xxxxx Title: Commissioner - Buildings and General Services Date: By: Name: Title: Date: Revision Date: 05/30/2019 STATE OF VERMONT CONTRACT AMENDMENT It is hereby agreed by and between the State of Vermont, Department of Buildings and General Services (the "State") and Xxxxx Electric, Inc., with a principal place of business in Colchester, VT (the "Contractor") that the contract between them originally dated as of November 1, 2018, Contract #37366, as amended to date, (the “Contract”) is hereby amended as follows:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!