SWORN CONSTRUCTION STATEMENT Sample Clauses

SWORN CONSTRUCTION STATEMENT. Prior to the initial disbursement hereunder, the Lessee shall have submitted to Lessor and Title a Construction Cost Statement or the Construction Contract (if such information is contained therein) sworn to by Lessee and Contractors reflecting all major Sub-Contractors or materialmen who shall then be engaged in furnishing labor, materials or supplies for the Improvements. The list should show the name of each and every Contractor, Sub-Contractor and materialman (or at least such entities or individuals whose contract is in excess of $5,000), its address and an estimate of the dollar value of the work, labor and materials to be done or supplied and a general statement of the nature of the work to be done or materials to be supplied by each Contractor. Thereafter, if such list should change or new subcontractors shall execute contracts not reflected on the above list, the Lessee shall furnish to the Lessor any amendments or additions to the original statement as so submitted.
AutoNDA by SimpleDocs
SWORN CONSTRUCTION STATEMENT. The Borrower shall furnish to the Lender an updated Sworn Construction Statement setting forth the Contractor(s) providing services or materials with respect to specific portions of the construction of the Project and setting forth the amounts actually incurred and paid, or to be incurred, in completing construction of the Project. Such updated Sworn Construction Statement shall be sworn to by the Borrower and the General Contractor to be a true, complete and accurate account of all costs actually incurred and an accurate estimate of all costs to be incurred in the future;
SWORN CONSTRUCTION STATEMENT. Prior to the initial disbursement hereunder, the Borrower shall have submitted to Lender and Title a Construction Cost Statement sworn to by Borrower and Contractor(s) and all major Sub-Contractors or materialmen who shall then be engaged in furnishing labor, materials or supplies for the Improvements. The list should show the name of each and every Contractor, Sub-Contractor and materialman, his address and an estimate of the dollar value of the work, labor and materials to be done or supplied and a general statement of the nature of the work to be done or materials to be supplied by each. The Borrower shall furnish to the Lender any amendments or additions to the original statement as so submitted. The Borrower shall also submit a sworn statement of all Loan and carrying charges certified to Lender.
SWORN CONSTRUCTION STATEMENT. If required by the Agent, the Borrower shall furnish to the Agent an updated Sworn Construction Statement setting forth the services or materials with respect to specific portions of the construction of the Project and setting forth the amounts actually incurred and paid, or to be incurred, in completing construction of the Project. Such updated Sworn Construction Statement shall be sworn to by the Borrower and the Design/Builder to be a true, complete and accurate account of all costs actually incurred and an accurate estimate of all costs to be incurred in the future; and
SWORN CONSTRUCTION STATEMENT. A sworn construction statement duly executed by the Borrower and the General Contractor showing all Contractors having contracts or subcontracts for specific portions of the work on the Improvements and the amounts due or to become due each such Contractor, and including all so-called "hard" costs of any kind incurred and to be incurred in constructing the Improvements and fulfilling the Table Of Contents obligations of the General Contractor under the terms of the General Contractor's Contract.
SWORN CONSTRUCTION STATEMENT. The Sworn Construction Statement.
SWORN CONSTRUCTION STATEMENT. With the initial Construction Advance, and with each subsequent advance following any change that effecting the items on the Sworn Construction Statement, Borrower shall furnish to Lender an updated Sworn Construction Statement setting forth the Contractor(s) providing services or materials with respect to specific portions of the construction of the Project and setting forth the amounts actually incurred and paid, or to be incurred, in completing construction of the Project. Such updated Sworn Construction Statement shall be sworn to by Borrower and the General Contractor to be a true, complete and accurate account of all costs actually incurred and an accurate estimate of all costs to be incurred in the future;
AutoNDA by SimpleDocs
SWORN CONSTRUCTION STATEMENT is the sworn statement of Borrower, together with the certificate of Borrower reflecting Construction Costs, in a form approved by and otherwise acceptable to the Bank.
SWORN CONSTRUCTION STATEMENT. Prior to the initial disbursement hereunder, the Lessee shall have submitted to Lessor and Title a Construction Cost Statement or the Construction Contract (if such information is contained therein) sworn to by Lessee and Contractors reflecting all major Sub-Contractors or materialmen who shall then be engaged in furnishing labor, materials or supplies for the Improvements. The list should show the name of each and every Contractor, (and with respect to further disbursements, if Lessee be in default hereunder, upon written request by Lessor, Lessee shall provide a list of Sub- Contractors and materialman (or at least such entities or individuals whose contract is in excess of $5,000)), its address and an estimate of the dollar value of the work, labor and materials to be done or supplied and a general statement of the nature of the work to be done or materials to be supplied by each Contractor. Thereafter, if such list should change or new Contractors shall execute contracts not reflected on the above list, the Lessee shall furnish to the Lessor any amendments or additions to the original statement as so submitted.

Related to SWORN CONSTRUCTION STATEMENT

  • Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).

  • Construction Schedule 5.1 Coordination:

  • Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.

  • Certain Constructions (a) For purposes of this Agreement, references to the most or next most subordinate Class of Non-Vertically Retained Pooled Regular Certificates outstanding at any time shall mean the most or next most subordinate Class of Non-Vertically Retained Pooled Regular Certificates then outstanding as among the Class A-1, Class A-2, Class A-3, Class A-4, Class A-5, Class A-AB, Class X-A, Class X-B, Class X-D, Class A-S, Class B, Class C, Class D, Class E, Class F-RR, Class G-RR and Class J-RR Certificates; provided, however, that for purposes of determining the most subordinate Class of Non-Vertically Retained Pooled Regular Certificates, in the event that the Class A-1, Class A-2, Class A-3, Class A-4, Class A-5 and Class A-AB Certificates are the only Classes of Non-Vertically Retained Pooled Principal Balance Certificates outstanding, the Class A-1, Class A-2, Class A-3, Class A-4, Class A-5, Class A-AB and Class X-A Certificates together will be treated as the most subordinate Class of Non-Vertically Retained Pooled Regular Certificates. For purposes of this Agreement, each Class of Certificates (other than the Class S and Class R Certificates) shall be deemed to be outstanding only to the extent its respective Certificate Balance or Notional Amount has not been reduced to zero. For purposes of this Agreement, the Class R Certificates shall be deemed to be outstanding so long as the Trust REMICs have not been terminated pursuant to Section 9.01 of this Agreement.

  • Interpretation; Construction The headings set forth in this Agreement are for convenience only and shall not be used in interpreting this Agreement. This Agreement has been drafted by legal counsel representing Company, but Executive has participated in the negotiation of its terms. Furthermore, Executive acknowledges that Executive has had an opportunity to review and revise the Agreement and have it reviewed by legal counsel, if desired, and, therefore, the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Agreement.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.

  • General Construction Principles Words in any gender are deemed to include the other genders. The singular is deemed to include the plural and vice versa. The headings and underlined paragraph titles are for guidance only and have no significance in the interpretation of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!