PLANT CLOSURE 29.01 In the event the Company closes the plant at the Cambridge location as a result of the loss of business or a discontinuation of all operations, severance pay will be calculated at one (1) week’s regular pay per year of service. The severance payment, so calculated, is inclusive of any severance payment required by the Ontario Employment Standards Act (Revised 2000). This agreement is not applicable to a sale of the business or if the closure is occasioned by a labour dispute.
Lane closure (i) The Contractor shall not close any lane of the Project Highway for undertaking maintenance works except with the prior written approval of the Authority’s Engineer. Such approval shall be sought by the Contractor through a written request to be made at least 10 (ten) days before the proposed closure of lane and shall be accompanied by particulars thereof. Within 5 (five) business days of receiving such request, the Authority’s Engineer shall grant permission with such modifications as it may deem necessary and a copy of such permission shall be sent to the Authority.
(ii) Upon receiving the permission pursuant to Clause 14.5 (i), the Contractor shall be entitled to close the designated lane for the period specified therein, and for all lane closures extending a continuous period of 48 (forty-eight) hours, the Contractor shall, in the event of any delay in re-opening such lane, for every stretch of 250 (two hundred and fifty) metres, or part thereof, pay Damages to the Authority calculated at the rate of 0.1% (zero point one per cent) of the monthly maintenance payment for each day of delay until the lane has been re-opened for traffic. In the event of any delay in re-opening such lanes or in the event of emergency decommissioning and closure to traffic of the whole or any part of the Project Highway due to failure of the Contractor, the Contractor shall pay damages to the Authority at double the above rate, without prejudice the rights of the Authority under this Agreement including Termination thereof.
System Upgrade Facilities and System Deliverability Upgrades Connecting Transmission Owner shall design, procure, construct, install, and own the System Upgrade Facilities and System Deliverability Upgrades described in Appendix A hereto. The responsibility of the Developer for costs related to System Upgrade Facilities and System Deliverability Upgrades shall be determined in accordance with the provisions of Attachment S to the NYISO OATT.
Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Provisioning Line Splitting and Splitter Space 3.8.1 The Data LEC, Voice CLEC or BellSouth may provide the splitter. When Southern Telecom or its authorized agent owns the splitter, Line Splitting requires the following: a non-designed analog Loop from the serving wire center to the NID at the End User’s location; a collocation cross connection connecting the Loop to the collocation space; a second collocation cross connection from the collocation space connected to a voice port; the high frequency spectrum line activation, and a splitter. The Loop and port cannot be a Loop and port combination (i.e. UNE-P), but must be individual stand-alone Network Elements. When BellSouth owns the splitter, Line Splitting requires the following: a non designed analog Loop from the serving wire center to the NID at the End User’s location with CFA and splitter port assignments, and a collocation cross connection from the collocation space connected to a voice port.
3.8.2 An unloaded 2-wire copper Loop must serve the End User. The meet point for the Voice CLEC and the Data LEC is the point of termination on the MDF for the Data LEC's cable and pairs.
3.8.3 The foregoing procedures are applicable to migration to Line Splitting Service from a UNE-P arrangement, BellSouth Retail Voice Service, BellSouth High Frequency Spectrum (CO Based) Line Sharing.
3.8.4 For other migration scenarios to line splitting, BellSouth will work cooperatively with CLECs to develop methods and procedures to develop a process whereby a Voice CLEC and a Data LEC may provide services over the same Loop.
Account Closure At any time, for any reason, we may take any of these actions subject to applicable law:
Participating TO’s Interconnection Facilities The Participating TO shall design, procure, construct, install, own and/or control the Participating TO’s Interconnection Facilities described in Appendix A at the sole expense of the Interconnection Customer. Unless the Participating TO elects to fund the capital for the Participating TO’s Interconnection Facilities, they shall be solely funded by the Interconnection Customer.
Testing of Metering Equipment Connecting Transmission Owner shall inspect and test all of its Metering Equipment upon installation and at least once every two (2) years thereafter. If requested to do so by NYISO or Developer, Connecting Transmission Owner shall, at Developer’s expense, inspect or test Metering Equipment more frequently than every two (2) years. Connecting Transmission Owner shall give reasonable notice of the time when any inspection or test shall take place, and Developer and NYISO may have representatives present at the test or inspection. If at any time Metering Equipment is found to be inaccurate or defective, it shall be adjusted, repaired or replaced at Developer’s expense, in order to provide accurate metering, unless the inaccuracy or defect is due to Connecting Transmission Owner’s failure to maintain, then Connecting Transmission Owner shall pay. If Metering Equipment fails to register, or if the measurement made by Metering Equipment during a test varies by more than two percent from the measurement made by the standard meter used in the test, Connecting Transmission Owner shall adjust the measurements by correcting all measurements for the period during which Metering Equipment was in error by using Developer’s check meters, if installed. If no such check meters are installed or if the period cannot be reasonably ascertained, the adjustment shall be for the period immediately preceding the test of the Metering Equipment equal to one-half the time from the date of the last previous test of the Metering Equipment. The NYISO shall reserve the right to review all associated metering equipment installation on the Developer’s or Connecting Transmission Owner’s property at any time.
Communications Equipment (a) Subject to the provisions of this Section 3.5, Tenant shall have the non-exclusive right, at its sole cost and expense and for Tenant’s use, to install, maintain and operate upon the roof of the Building one (1) or a reasonable and necessary additional number of transmitters and/or receiver antennas or dishes approved by Landlord, which approval shall not be unreasonably withheld or delayed (collectively, the “Communications Equipment”) for use by Tenant in the conduct of its business; provided that such Communications Equipment may not materially compromise the aesthetics or appearance of the Building nor shall Landlord be required to incur any expense in accommodating the Communications Equipment. The Communications Equipment must be (i) designed, installed and operated in compliance with all Legal Requirements, and (ii) installed and operated so as not to adversely affect or impact structural, mechanical, electrical, elevator, or other systems serving the Building or customary telephone service for the Building and so as not to cause injury to persons or property, and without limitation of the foregoing, so as not to void or impair any applicable roof warranty. Upon the expiration or termination of this Lease, Tenant shall remove the Communications Equipment and repair any damage to the Building caused by the installation, maintenance, use or removal of the Communications Equipment.
(b) Landlord hereby grants to Tenant the right to install (at Tenant’s sole cost and expense) any additional equipment required to operate the Communications Equipment and to connect the Communications Equipment to Tenant’s other machinery and equipment located in the Leased Premises (e.g., conduits and cables) in the shafts, ducts, chases and utility closets located in the core of the building (“Additional Equipment”), which Additional Equipment shall be deemed a part of the Communications Equipment for all purposes of this Section 3.5; provided that (i) the use of such space in the Building core by Tenant (except customary chases for cabling) may not materially adversely affect the marketability of the remaining space on any floor of the Building, and (ii) to the extent any such Additional Equipment occupies space (other than space in customary chases for the Building) that would have otherwise been Net Rentable Area on a floor of the Building, such space shall be included within the Net Rentable Area of the Leased Premises and Tenant shall be obligated to pay Annual Basic Rent and Additional Rent with respect to such space as if such space was included in the Leased Premises. Tenant’s use of such space in the Building core shall be subject to the provisions of this Lease relating to Tenant’s use of Common Areas of the Building.
(c) Subject to the Building Rules and other reasonable rules relating to Building security and safety that may be promulgated by Landlord pertaining to access by tenants to the roof of the Building and provided Tenant does not unreasonably disturb any other tenants of the Building, Tenant and Tenant’s contractors shall have reasonable access to the Communications Equipment and the Additional Equipment for purposes of operating, servicing, repairing or otherwise maintaining said equipment.
(d) Nothing contained in this Section 3.5 shall be deemed to prohibit or restrict any other individual or entity, including Landlord or any other tenant of the Building, from installing communications equipment on the roof of the Building or to use the roof for any other purpose.
(e) In connection with its installation, repair, maintenance and removal of any Communications Equipment and Additional Equipment, Tenant, at Tenant’s sole cost and expense, shall comply with all applicable Building Rules and Legal Requirements and repair any damage to the Building caused by such installation, repair, maintenance or removal. In the event that the placement of Tenant’s Communications Equipment or Additional Equipment interferes with Landlord’s performance of any repair or maintenance to the Common Areas, including the roofs of the Buildings, any costs incurred by Landlord to temporarily or permanently relocate and reinstall Tenant’s Communications Equipment or Additional Equipment shall be included in the cost of such repair or maintenance as a Operating Expense.
(f) Tenant’s Communications Equipment and Additional Equipment existing as of the Commencement Date are hereby deemed to be approved by Landlord. Any changes to the existing Communications Equipment and/or Additional Equipment by Tenant shall first be approved by Landlord, which approval will not be unreasonably withheld or delayed.
(g) If Landlord shall place on the roof of any Building communications equipment of its own, or shall grant to any third party the right to locate and maintain any such equipment, all such equipment shall be located, designed and operated so as not to interfere with signals to and from Tenant’s Communications Equipment and Additional Equipment, the installation of which, in accordance with this Section 3.5, predates the installation of such other equipment. Similarly, any Communications Equipment and Additional Equipment hereafter installed by Tenant shall be located and designed so as not to interfere with signals to and from such other equipment belonging to Landlord or to third parties, that may have previously been installed. The party responsible for the communications equipment which interferes with equipment previously installed by others shall be required, at its or their expense, to take all measures necessary to eliminate the source of interference caused by such party’s equipment.
