Lane Closure definition

Lane Closure means closure of any traffic lane, or the reduction in width of any traffic lane to less than the widths specified in Section 26.2.1 of the Design-Build Specifications, in any portion of the Project or a connecting highway, as applicable, and for any duration, including main lanes, ramps, direct connectors, frontage roads, access roads and cross roads.

Lane Closure means full or partial closure of any traffic lane in any portion of the Project and for any duration, including main lanes, ramps, direct connectors, frontage roads and cross roads.

Lane Closure means a circumstance where the minimum width of Lane required in accordance with Chapter 8 of the Traffic Signs Manual to permit passage by all classes of vehicle is not available.

Examples of Lane Closure in a sentence

• No Lane Closure that restricts or interferes with traffic shall be allowed from 12:00 PM (noon) on the day preceding to 12:00 AM (midnight) on the day after the regional event and holiday schedule dates set forth in Section 4.1.17.2.3 of the CMA General Conditions.

• For each Lane Closure, a determination shall be made of the applicable hourly Lane Rental Charge using the amounts shown on Table 8-2.

• Lane Closures are only allowed during Off-Peak Periods if the Lane Closure is requested by DB Contractor and approved by TxDOT in its sole discretion.

• If DB Contractor fails to properly identify and timely address the hazard mitigation for a Category 1 Defect as described in Section 9.4.5 of the CMA Specification, then notwithstanding that the affected travel lane(s) remain open to traffic TxDOT shall have the right to assess a Lane Rental Charge for a Lane Closure for the relevant travel lane until the hazard to Users has been mitigated.

• The deduction from each monthly payment for Maintenance Services as set forth in Section 8.2 of the CMA General Conditions shall be the sum during the prior month for each Lane Closure of the applicable hourly Lane Rental Charge multiplied by the number of lanes closed multiplied by the number of hours the Lane Closure was in effect.

More Definitions of Lane Closure

Lane Closure means a closure of an individual lane or lanes for the purposes of work while maintaining traffic flow in the direction of travel.

Lane Closure means any Closure affecting a lane or lanes within the Pattullo Mainline, the Highway 17 Mainline, a Ramp, a Specified Road or an Other Street, but excludes a Full Closure.

Lane Closure means any partial or total closure or other restriction of one or more lanes of traffic (in one direction of travel) using the Project Road, but excluding any Type C lane closures (as defined in Section 6 of Chapter 8 of the Traffic Signs Manual) and for the avoidance of doubt, traffic congestion or slow moving traffic on the Project Road shall not be considered in and of itself to be a partial or total closure of a lane of traffic.

Lane Closure means closure of any traffic lane, or the reduction in width of any traffic lane to less than the widths specified in Section 26.2.1.2 of the Design-Build Specifications, in any portion of the Project or a connecting highway, as applicable, and for any duration, including main lanes, ramps, direct connectors, frontage roads, access roads and cross roads. Liquidated Damages means the liquidated damages, including Liquidated Damages for Delay, Key Personnel Unavailability Liquidated Damages and Liquidated Damages for Lane Closures, specified in DBA Sections 7.2, 7.3 and 7.4, and General Conditions Sections 8.3.1, 8.7.1.1 and 8.7.2.1.

Lane Closure means full or partial closure of any traffic lane in any portion of the Project or a connecting highway, as applicable, and for any duration, including main lanes, ramps, direct connectors, frontage roads and cross roads. Law or Laws means (a) any statute, law, code, regulation, ordinance, rule or common law, (b) any binding judgment (other than regarding a Claim or Dispute), (c) any binding judicial or administrative order or decree (other than regarding a Claim or Dispute), (d) any written directive, guideline, policy requirement or other governmental restriction (including those resulting from the initiative or referendum process, but excluding those by TxDOT within the scope of its administration of the Contract Documents) or (e) any similar form of decision of or determination by, or any written interpretation or administration of any of the foregoing by, any Governmental Entity, in each case which is applicable to or has an impact on the Project or the Work, whether taking effect before or after the Effective Date, including Environmental Laws. “Laws”, however, excludes Governmental Approvals.

Lane Closure has the meaning given in Schedule 34 – Mobility Matters.

Lane Closure means a closure of one or more lanes on a roadway such that the direction of traffic flow is maintained in all directions existing before the closure and no diversion of traffic to another road is required;