Project Coordination The Engineer shall coordinate all subconsultant activity to include quality and consistency of deliverables and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.
Engineer's Coordination with Owner Engineer shall be available for conferences with City so that Project can be designed with the full benefit of City's experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. City shall make available to Engineer all existing plans, maps, field notes, and other data in its possession relative to the Project. Engineer may show justification to City for changes in design from City standards due to the judgment of said Engineer of a cost savings to City and/or due to the surrounding topographic conditions. City shall make the final decision as to any changes after appropriate request by Engineer.
Project Management and Coordination The Engineer shall coordinate all subconsultant activity to include quality of and consistency of work and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.
Project Management Plan 1 3.4.1 Developer is responsible for all quality assurance and quality control 2 activities necessary to manage the Work, including the Utility Adjustment Work.
Project Monitoring Reporting and Evaluation The Recipient shall furnish to the Association each Project Report not later than forty-five (45) days after the end of each calendar semester, covering the calendar semester.
Project Implementation 2. The Borrower shall:
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Project Monitoring The Developer shall provide regular status reports to the NYISO in accordance with the monitoring requirements set forth in the Development Schedule, the Public Policy Transmission Planning Process Manual and Attachment Y of the OATT.
Project Monitoring Reporting Evaluation A. The Project Implementing Entity shall monitor and evaluate the progress of its activities under the Project and prepare Project Reports in accordance with the provisions of Section 5.08(b) of the General Conditions and on the basis of indicators agreed with the Bank. Each such report shall cover the period of one
Project Coordinator 3. Within 14 days of the effective date of this Consent Agreement, DTSC and Respondent shall each designate a Project Coordinator and shall notify each other in writing of the Project Coordinator selected. Each Project Coordinator shall be responsible for overseeing the implementation of this Consent Agreement and for designating a person to act in his/her absence. All communications between Respondent and DTSC, and all documents, report approvals, and other correspondence concerning the activities performed pursuant to this Consent Agreement shall be directed through the Project Coordinators. Each party may change its Project Coordinator with at least seven days prior written notice. WORK TO BE PERFORMED
