Technical Support Services 2.1 The technical support services (the "Services"): Party A agrees to provide to Party B the relevant services requested by Party B, which are specified in Exhibit 1 attached hereto ("Exhibit 1").
Technical Support State Street will provide technical support to assist the Fund in using the System and the Data Access Services. The total amount of technical support provided by State Street shall not exceed 10 resource days per year. State Street shall provide such additional technical support as is expressly set forth in the fee schedule in effect from time to time between the parties (the “Fee Schedule”). Technical support, including during installation and testing, is subject to the fees and other terms set forth in the Fee Schedule.
Operational Support Systems (OSS The terms, conditions and rates for OSS are as set forth in Section 2.13 of this Attachment.
Operational Support Systems <<customer_name>> shall pay charges for Operational Support Systems (OSS) as set forth in this Agreement in Attachment 1 and/or in Attachments 2, 3 and 5, as applicable.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor.
12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.
Operations Support Systems (OSS)
47.1. Embarq will offer unbundled access to Embarq’s operations support systems to the extent technically feasible in a non-discriminatory manner at Parity. OSS consists of pre- ordering, ordering, provisioning, maintenance and repair, and billing functions supported by Embarq’s databases and information. The OSS element includes access to all loop qualification information contained in Embarq’s databases or other records, including information on whether a particular loop is capable of providing advanced services.
Operational Support 2.1 Party A agrees, according to the operational needs of Party B, to act as the guarantor of Party B in the contracts, agreements, or transactions entered into between Party B and third parties, in order to fully guarantee the performance by Party B of such contracts, agreements, and transactions.
2.2 Party A agrees, according to the operational needs Party B, to recommend directors and senior management to Party B and Party B agrees to appoint such personnel recommended by Party A to be its directors and senior management. The relevant personnel recommended by Party A pursuant to this Article shall meet the qualification requirements for directors and senior management under applicable laws.
2.3 To ensure the performance of this Agreement, Party A agrees to provide to Party B cooperative policy advice and guidance, which is consistent with the daily operation and financial management and the employment policy of Party B.
