Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
Temporary Space Upon reasonable prior notice from Tenant to Landlord, Landlord agrees to provide Tenant with temporary space (the "Temporary Space") on either the second floor of Building A or the second floor of Building B of a size and in a location to be mutually agreed upon by Landlord and Tenant for a period of time commencing no earlier than sixty (60) days from the date of Tenant's notice requesting that the Temporary Space be made available and expiring on the Commencement Date of this Lease. Tenant's occupancy of the Temporary Space shall be subject to all of the terms and conditions of this Lease to the extent appropriate, except that (i) Annual Fixed Rent for the Temporary Space shall be payable at the annual rate equal to the product of (x) $4.00 and (y) the rentable floor area of the Temporary Space, (ii) for the purposes of determining Tenant's payments on account of Landlord's Operating Expenses under Section 2.6 above and Landlord's Tax Expenses under Section 2.7 with respect to the Temporary Space, the "Rentable Floor Area of the Premises" shall be deemed to be the rentable floor area of the Temporary Space and (iii) the Temporary Space shall be delivered to Tenant in its "as is" condition and no improvement allowance or brokerage commission shall be payable with respect thereto. In addition, it is acknowledged and agreed that if Tenant shall elect to lease any Temporary Space hereunder, Tenant shall be occupying such Temporary Space while Landlord is proceeding with components of the Base Building Work in Buildings A and B and accordingly that Tenant shall use and occupy the Temporary Space in such as manner as to minimize any unreasonable interference with Landlord's performance of the Base Building Work. EXECUTED as a sealed instrument in two or more counterparts each of which shall be deemed to be an original. WITNESS: LANDLORD: BOSTON PROPERTIES LIMITED PARTNERSHIP By: Boston Properties, Inc., its general partner By: --/s/ Xxxxx RosenName: Xxxxx RosenTitle: Senior Vice President, Development TENANT ATTEST: By: By: /s/ Xxxxx Xxxxx Name: Name: Xxxxx Xxxxx Title: Secretary or Assistant Secretary Title: President or Vice President Hereto duly authorized By: Name: Title: Treasurer or Assistant Treasurer Hereto duly authorized Those certain parcels of land (with the buildings thereon) situated in Bedford, Middlesex County, Massachusetts bounded and described as follows: PARCELS 1 and 2 Two certain parcels of land situated in Bedford, Middlesex County, Massachusetts, shown as Lot 1 and 2 on a plan entitled “Plan of Land in Bedford, Mass." dated March 1, 1962 by Xxxxxxx X. Xxxxxxx, Inc., recorded with Middlesex South District Deeds as Plan No. 487 of 1962 in Book 10022, Page 278, and together bound and described as follows: SOUTHWESTERLY by Xxxxxx Road by three lines measuring respectively two hundred eighty-three and 011100 (283.01) feet, twenty-one and 271100 (21.27) feet and four hundred eighty-three and 43/100 (483.43) feet; thence SOUTHERLY by said Xxxxxx Road by a curved line, one hundred nineteen and361100 (119.36) feet; thence SOUTHEASTERLY SOUTHERLY and SOUTHWESTERLY by said Xxxxxx Road by several lines measuring respectively two hundred ninety-three and 04/100 (293.04) feet, three hundred fifty three and 041100 (353.04) feet and two hundred twenty and 97/100 (220.97) feet; thence NORTHEASTERLY by the parcel marked "Reserved for Town of Bedford" on said plan, sixteen hundred forty-six and 81/100 (1646.81) feet; and thence NORTHWESTERLY by land now or late of The Worcester Corp., by two lines measuring respectively 305.23 feet and 294.24 feet and by land now or late of Xxxxxxx by two lines measuring respectively 170.33 feet and 64.34 feet, to the place of beginning. For Title see Deed recorded with the Middlesex South District Registry of Deeds in Book 12926, Page 233. PARCEL 3 A certain parcel of land situated in said Bedford, shown on a plan of land in Bedford, Mass.Dated June 5, 1961 by Xxxxxxx X. Xxxxxxx, Inc., Registered Land Surveyors, recorded with Middlesex South District Registry of Deeds at the end of Book 9844, bounded and described as follow: SOUTHWESTERLY by Xxxxxx Road, two hundred ninety-eight and 63/100 (298.63) feet; NORTHWESTERLY by land now or formerly of the Worcester Corporation, two hundred nine and 95/100 (209.95) feet; NORTHEASTERLY by land now or formerly of the Worcester Corporation, two hundred fifty and 57/100 (250.57) feet; and SOUTHEASTERLY by land now or formerly of Sinbad Realty Corporation by two lines respectively measuring one hundred seventy and 33/100 (170.33) feet and sixty-four and 341100(64.34) feet. Containing approximately 60,951 square feet of 1.4 acres according to said plan. For Title see Deed from Xxxxx X. Xxxxxxx and Xxxxxxxxx X. Xxxxxxx recorded with the Middlesex South District Registry of Deeds in Book 13539, Page 732. PARCEL 4 All right, title and interest in and to (i) that portion of Xxxxxx Road described in that certain Deed (a) recorded with the Middlesex South District Registry of Deeds in Book 14013, Page 486 and (b) filed with the Middlesex South Registry District of the Land Court as Document No. 599584 as to which Certificate of Title No. 161163 in Registration Book 936, Page 13 was issued; and
Temporary Work Temporary work results from replacing a faculty member on leave, or assigned to other duties, or work that is a result of a time limited contract/project.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Temporary Upgrade An employee in a temporary upgrade status shall have no right to grieve or arbitrate release from such temporary upgrade status.
Temporary Position (i) is a position that the Employer has determined will be in excess of eight
Temporary Positions A) The Employer may create regular temporary positions for vacation relief for more than one (1) incumbent for up to six (6) months duration. B) The Employer may create regular temporary project positions (i.e. grant funded, capital projects, pilot projects, or term specific assignments) for up to twelve (12) months’ duration. These positions are not renewable after the end date of the project, unless the Union and Employer agree to renew/extend the time limits. C) These positions will be posted and filled in accordance with Article 17.01-
Temporary Roads As necessary to attain stabilization of roadbed and fill slopes of Temporary Roads, Purchaser shall employ such measures as out- sloping, drainage dips, and water-spreading ditches.
Temporary Reduction of Rent If the Property is destroyed or damaged and Landlord or Tenant repairs or restores the Property pursuant to the provisions of this Article Seven, any rent payable during the period of such damage, repair and/or restoration shall be reduced according to the degree, if any, to which Tenant's use of the Property is impaired. However, the reduction shall not exceed the sum of one year's payment of Base Rent, insurance premiums and real property taxes. Except for such possible reduction in Base Rent, insurance premiums and real property taxes, Tenant shall not be entitled to any compensation, reduction, or reimbursement from Landlord as a result of any damage, destruction, repair, or restoration of or to the Property.
PARTIAL OCCUPANCY OR USE 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Paragraph 11.3.1.5, the surety, and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit a list to the Architect as provided under Paragraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. 9.9.2 Immediately prior to partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. 9.9.3 Partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents.
