Compensation to NCPS (a) Issuer Party shall pay or cause to be paid to NCPS for its services as the facilitator of escrow as outlined in Exhibit B, which may be updated from time to time by NCPS by providing written notice to Issuer Party. Issuer Party’s obligation to pay such fees to NCPS and reimburse NCPS for such expenses is not conditioned upon a successful closing. Upon Issuer Party’s request, NCPS will provide Issuer Party with copies of all relevant invoices, receipts or other evidence of such expenses. The obligations of Issuer Party under this Section 10 shall survive any termination of this Agreement and the resignation or removal of NCPS.
(b) All of the compensation and reimbursement obligations shall be payable by Issuer Party upon demand by NCPS and will be charged automatically by NCPS to the credit card or other payment method separately provided or as otherwise agreed by the Parties. Issuer Party consents to NCPS retaining and using Issuer Party’s payment information for future invoices and as provided in this Agreement. Issuer Party agrees and acknowledges that NCPS and its third party vendors may retain and use Issuer Party’s payment information to facilitate the payments provided for in this Agreement. Issuer Party agrees to provide NCPS written notice (which may be via email) of any update or changes to Issuer Party’s payment information. Absent current payment information, Issuer Party shall make, or cause to be made, all payments to NCPS within 10 days of receiving an invoice therefor. All payments made to NCPS shall be in US dollars in immediately available funds.
(c) If Issuer Party fails to make any payment when due then, in addition to all other remedies that may be available: (a) NCPS may charge interest on the past due amount at the rate of 1.5% per month, calculated daily and compounded monthly, or if lower, the highest rate permitted under Law, which Issuer Party shall pay; such interest may accrue after as well as before any judgment relating to collection of the amount due; and (b) Issuer Party shall reimburse, or cause to be reimbursed, NCPS for all costs incurred by NCPS in collecting any late payments or interest, including attorneys’ fees, court costs and collection agency fees; provided that cumulative late payments are subject to the overall limits as may be required by Law as set forth in Exhibit B.
(d) Only upon the fulfillment of the Minimum Offering, and only when Escrowed Funds are eligible to be released to Issuer in accordance with Section 4(a), and otherwise in compliance with Law, NCPS is authorized to and may disburse from time to time, to itself or to any NCPS Party from the Escrow Funds (but only to the extent of Issuer’s rights thereto), the amount of any compensation and reimbursement of out-of-pocket expenses due and payable hereunder (including any amount to which NCPS or any NCPS Party is entitled to seek indemnification pursuant to Section 9 hereof). NCPS shall notify Issuer Party of any disbursement from the Escrow Funds to itself or to any NCPS Party in respect of any compensation or reimbursement hereunder and shall furnish to Issuer copies of all related invoices and other statements.
(e) Only upon the fulfillment of the Minimum Offering, and only when Escrowed Funds are eligible to be released to Issuer in accordance with Section 4(a), and otherwise in compliance with Law, Issuer shall grant to NCPS and the NCPS Parties a security interest in and lien upon such Escrow Funds (but only to the extent of Issuer’s rights thereto) to secure all obligations hereunder, and NCPS and the NCPS Parties shall have the right to offset the amount of any compensation or reimbursement due any of them hereunder (including any claim for indemnification pursuant to Section 9 hereof) against the Escrow Funds (but only to the extent of Issuer’s rights thereto). If for any reason the Escrow Funds available to NCPS and the NCPS Parties pursuant to such security interest or right of offset are insufficient to cover such compensation and reimbursement, Issuer Party shall promptly pay such amounts to NCPS and the NCPS Parties upon receipt of an itemized invoice.
Basic Compensation (a) SALARY. Executive will be paid an annual base salary of $115,000.00, subject to adjustment as provided below (the "Salary"), which will be payable in equal periodic installments according to Employer's customary payroll practices, but no less frequently than monthly. The Salary will be reviewed by the Board of Directors not less frequently than annually, and shall be increased on each anniversary of the Effective Date during the term hereof by an amount equal to not less than ten percent (10%) of the prior year's base salary.
A-E Compensation and Extra Work 1.5.1. For the PROJECTS/SERVICES authorized under this CONTRACT, A-E shall be compensated in accordance with the following:
1.5.2. For completion and approval of all PROJECTS/SERVICES where “Extra Work” (defined as changes in approved portions of the PROJECT/SERVICES required by and ordered in writing by DIRECTOR which changes constitute a change in or departure from said approved portions of PROJECTS/SERVICES) is not authorized, compensation including reimbursables shall be described and payable as stipulated in Fee Schedule, herein after referred to as “Attachment B”, attached hereto and incorporated herein by reference.
1.5.3. Where extra work is authorized for PROJECTS/SERVICES:
a. The amount for Extra Work shall be determined using Attachment B. Extra Work shall be required by and ordered in writing by DIRECTOR. If this CONTRACT is not approved by the Board of Supervisors, any change that increases the cumulative CONTRACT price beyond $100,000 must be approved by the Board. Increases in the CONTRACT amount for services within the existing scope of work may be granted by the DIRECTOR where the amount does not exceed 25 percent of the existing CONTRACT price or $100,000, whichever is less.
b. A-E's billing for the Extra Work shall include but not be limited to names of A- E's staff employed in the Extra Work, classification of employees and number of hours worked.
1.5.4. For partial completion of work of PROJECTS/SERVICES followed by default on part of A-E:
a. For failure to complete and secure approval of the first required submittal, there shall be no compensation.
b. For failure to complete and secure approval of other authorized phases, A-E shall, upon completion of PROJECTS/SERVICES by others, be entitled to receive compensation based on approved work of PROJECTS/SERVICES not to exceed the amounts specified in Attachment A for that particular submittal, plus the reasonable value as determined by COUNTY of the non-approved work; provided, however, that if the cost to COUNTY to complete the contract exceeds the amount specified herein, A-E shall be liable to COUNTY for such excess costs attributable to A-E's breach of the CONTRACT.
ADDITIONAL COMPENSATION AND BENEFITS The Executive shall receive the following additional compensation and welfare and fringe benefits:
Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.
Supplemental Compensation Pursuant to Section 7 of the Agreement, Supplemental Compensation is payable as follows.
Reduction of Compensation If the Firm fails to meet the submission date by less than thirty days for the draft report and/or working papers submitted to the Office of the State Auditor for review and approval or by less than thirty days from the completion date for the final reports and/or corrections to the working papers prescribed herein, the District may, with the consent of the Office of the State Auditor, reduce the agreed compensation by an amount not to exceed ten percent of the total contract price for the applicable fiscal year. If reports and/or corrections to the working papers are overdue by 30 days or more, the District may reduce, with the consent of the Office of the State Auditor, the agreed compensation by an amount not to exceed twenty percent of the total contract price for the Rev. 10/20 applicable fiscal year.
Term and Maximum Compensation 1.4.1. The term of this CONTRACT is for three (3) years, commencing upon Board of Supervisor approval, with a maximum allowable compensation of one million, five hundred thousand dollars ($1,500,000), with the option to renew for two (2) additional years, with Board approval; except as permitted in Paragraph 1.5 below.
Special Compensation The Company shall pay to the Executive a lump sum equal to three times the sum of (a) the highest per annum base rate of salary in effect with respect to the Executive during the three-year period immediately prior to the termination of employment plus (b) the Highest Bonus Amount. Such lump sum shall be paid by the Company to the Executive within ten business days after the Executive's termination of employment, unless the provisions of Section 3(e) below apply. The amount of the aggregate lump sum provided by this Section 3(c), whether paid immediately or deferred, shall not be counted as compensation for purposes of any other benefit plan or program applicable to the Executive.
Termination Compensation Termination Compensation equal to two (2) times the Executive's Base Period Income shall be paid to the Executive in a single sum payment in cash on the thirtieth (30th) business day after the later of (a) the Control Change Date and (b) the date of the Executive's employment termination; provided that if at the time of the Executive's termination of employment the Executive is a Specified Employee, then payment of the Termination Compensation to the Executive shall be made on the first day of the seventh (7th) month following the Executive's employment termination.
