Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant’s Space Plans Tenant shall deliver to Landlord and the TI Architect schematic drawings and outline specifications (the “TI Design Drawings”) detailing Tenant’s requirements for the Tenant Improvements within 5 business days of the date hereof. Not more than 2 days thereafter, Landlord shall deliver to Tenant the written objections, questions or comments of Landlord and the TI Architect with regard to the TI Design Drawings. Tenant shall cause the TI Design Drawings to be revised to address such written comments and shall resubmit said drawings to Landlord for approval within 2 days thereafter. Such process shall continue until Landlord has approved the TI Design Drawings.
Tenant’s Plans Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “Tenant’s Plans”) necessary to construct the Relocation Premises for Tenant’s occupancy, which plans shall be submitted to Landlord for approval by Landlord’s architect and engineers on or before June 1, 2012, and Tenant’s Plans shall comply with their requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s architect and engineers shall respond to any plan submission by Tenant within five (5) Business Days after Landlord’s receipt thereof. In the event Landlord’s architect’s or engineers’ approval of Tenant’s Plans is withheld or conditioned (and such approval shall not be unreasonably withheld or conditioned), Landlord shall send written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord within ten (10) days after receipt of Landlord’s notice of disapproval. Such process shall be followed until the plans shall have been approved by the Landlord’s architect and engineer without unreasonable objection or condition, except that after the initial five-(5)-Business-day period, any further submissions/resubmissions shall be made within three (3) Business Days. If Landlord fails to respond to submitted plans within the applicable period set forth above, then the September 10, 2012, date set forth in the table incorporated in Section III.A below shall be extended on a day-for-day basis for each day that any such failure continues. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Relocation Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s Plans shall in no event relieve Tenant of the responsibility for such design. Tenant shall be solely responsible for the timely preparation and submission of all such Tenant Plans and for all elements of the design of such Tenant’s Plans and for all costs related thereto. (The word “architect” as used in this Section II (C) shall include an interior designer or space planner.)
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
